Trans Canada Hwy. No.1 Donald Bridges and Approaches

Size: px
Start display at page:

Download "Trans Canada Hwy. No.1 Donald Bridges and Approaches"

Transcription

1 Ministry of Transportation and Infrastructure REQUEST FOR EXPRESSION OF INTEREST Project Number Trans Canada Hwy. No.1 Donald Bridges and Approaches Conceptual and Detailed Bridge Design & Functional and Detailed Highway Design Issue date: September 12, 2008 Closing Location: MAIL/COURIER/BY HAND: Bridge and Structural Engineering Ministry of Transportation and Infrastructure Southern Interior Region Columbia Street Kamloops, BC V2C 2T3 Attn: Laurie Christiansen, P.Eng. Manager, Bridge & Structural Engineering Closing Date and Time: Four (4) complete bound copies and one (1) electronic in pdf format of each Response must be received by: 2:00 pm Pacific Time on October 6, 2008 Contact Person: Laurie Christiansen, P.Eng. Fax: (250)

2 Table of Contents 1. OVERVIEW OF THE REQUIREMENT Project Description and Objectives REQUEST FOR EXPRESSION OF INTEREST Enquiries Closing Date Late Responses Qualifications Review Committee Evaluation and Selection... 6 Declaration Letter Changes to Response Wording Respondents Expenses Acceptance of Responses Definition of Contract List of Short Listed Respondents Not Binding Modification of Terms Ownership of Responses Confidentiality of Information Receipt Confirmation Form Respondents Meeting Examination and Interpretation of Documents SERVICES PROPOSED SCHEDULE FORM OF CONTRACT EVALUATION CRITERIA Evaluation Process Mandatory Criteria Desirable Criteria RESPONDENT'S RESPONSE APPENDIX A RECEIPT CONFIRMATION FORM

3 1. Overview of the Requirement The Ministry of Transportation and Infrastructure (TRAN), Southern Interior Region is soliciting expressions of interest from qualified engineering firms to provide engineering services for the functional and detailed design and construction engineering services for the upgrading of approximately 4.4 kilometres of the Trans Canada Highway, including the conceptual and detailed designs for the new Donald Bridge and Donald Overhead. The purpose of this Request for Expression of Interest (RFEOI) is to solicit statements of interest (Responses) from engineering companies (Respondents) interested in providing the engineering services to carry out this assignment, which is to be completed in the following phases; Phase 1: Functional Highway Design and Conceptual Bridge Design; Phase 2: Detailed Highway and Bridge Designs; Phase 3: Construction Engineering Services. The Ministry, at the completion of Phase 1, will make a final determination, depending on the availability of the funding, to either proceed to Phase 2 and 3 of the project assignment or to terminate the contract. For this project, the delivery of the designs within the timelines identified in Section 4 of this RFEOI is critical. The Ministry will only Short List engineering companies who, through their Responses, are qualified to undertake the work and that can adequately demonstrate their ability to provide the services within the allotted time frame. Other factors, as described in Sections 6, will be used to determine the most suitable engineering companies. The RFEOI Responses will be evaluated in accordance with Section 6 of this RFEOI. Based on the evaluation, the Ministry intends to establish a Short List of three (3) Respondents who, in the sole opinion of the Ministry, best meet the listed criteria. The Short Listed Respondents will be invited to submit proposals in response to a Request for Proposal (RFP) to be issued by the Ministry for this project. Ultimately, the Ministry intends to select one of the three Short Listed Respondents, based on the evaluation of the responses to the RFP and to enter into a Consulting Services Contract to deliver this assignment. 1.1 Project Description and Objectives The Project is located approximately 25km west of Golden along the Trans Canada Highway No. 1, starting at the western end of the existing west approach to the Donald Bridge, continuing eastward and crossing the existing Canadian Pacific Railway mainline through the area known as Donald, and connecting to the recently completed JUVIS Project on the east end (LKI Segment 0985, km 29.0 to km 33.4)

4 The general project location and its scope are shown on Figure 1 and Figure 2 below. -4-

5 The objective of the project is to increase capacity, improve safety and to facilitate economic development through this section of the Trans Canada Highway. As part of the Ministry s strategy for this corridor, all designs will incorporate a four lane template, include provisions for access management and intersection improvements, provide safety upgrades and enhance the potential for economic development along the corridor. This corridor has been identified by the Province as the priority transportation corridor in recognition of the Highway s importance for the movement of people and goods, and its importance as a vital link for commercial transport, tourism, and general inter-provincial and local traffic. This forms the basis of the Donald Bridges Project as a priority project within the corridor in recognition of the poor highway alignment and low design speed leading to a history of severe safety difficulties. In addition, the present timing within the two bridge s maintenance and rehabilitation cycles, in conjunction with the present provincial and federal focus on this corridor, makes this an opportune time to upgrade this critical section of highway. Numerous studies have considered various upstream and downstream alignment options in conjunction with several bridge rehabilitation and bridge replacement combinations. The basic conclusions drawn from these various studies are: Upgrading of the Donald Bridges Project section of the Trans Canada Highway is clearly required. Upgrading highway and bridges from the 2-lane 80 kmh design speed to present TAC standard 4-lane 100 kmh design speed is preferred. The preferred replacement option for the Donald Bridge is a single, multi span 4- Lane bridge at the upstream (south) side of the existing bridge. The successful consultant will be expected to continue to advance the work on the options described above. 2. Request For Expression of Interest (RFEOI) 2.1 Enquiries All enquires related to this RFEOI shall be directed, in writing (including ), to the Contact Person: Laurie Christiansen, P.Eng., Manager Bridge & Structural Engineering ( Laurie.Christiansen@gov.bc.ca) at the address provided on the front cover of this RFEOI. Information obtained from any other source is not official and shall not be relied upon. Enquiries and answers will be recorded and may be distributed to all Respondents at the Ministry s option. 2.2 Closing Date - 5 -

6 Responses must be received by 2:00 pm, local time, on October 3, 2008 at the address provided on the front cover of this RFEOI. 2.3 Late Responses Late Responses will not be accepted and will be returned, unopened, to the Respondent. 2.4 Qualifications Review Committee Evaluation of Responses will be conducted by a committee to be selected by the Ministry which may include employees as well as contractors of the Ministry. 2.5 Evaluation and Selection The Response evaluation committee will check Responses against the mandatory criteria. Responses not meeting all mandatory criteria will be rejected, at the Ministry s sole discretion, without further consideration. Responses that meet all the mandatory criteria will then be evaluated and scored against the desirable criteria. 2.6 Declaration Letter The Response must include a declaration letter, signed by a person authorized to sign on behalf of the Respondent, which binds the Respondent to statements made in response to this RFEOI. If the Respondent is a partnership or joint venture, a single letter of declaration must be furnished and endorsed by an authorized officer of the company from each partner or joint venture, stating that the company agrees to be jointly bound to statements made in response to this RFEOI. The declaration letter must also state that: The Respondent has read and understands the terms of the RFEOI; The Respondent understands the commitments made on their behalf in the Response; and The Respondent has the authorization to make the commitments set out in the Response. 2.7 Changes to Response Wording The Respondent shall not change the wording of its Response after Closing and no words or comments will be added to the Response unless requested by the Ministry for purposes of clarification. 2.8 Respondents Expenses Respondents are solely responsible for their own expenses in preparing a Response and for any subsequent negotiations with the Ministry. The Ministry will not be liable to any Respondent for any claims, whether for costs or damages incurred by the - 6 -

7 Respondent in preparing the Response, loss of anticipated profit in connection with any final Contract or any other matter whatsoever. 2.9 Acceptance of Responses This RFEOI is not an agreement to purchase goods or services. The Ministry is not bound to enter into a Contract with any Respondent. Responses will be evaluated using the mandatory and desirable criteria provided herein. The Ministry will be under no obligation to receive further information, whether written or oral, from any Respondent Definition of Contract Notice in writing to a Respondent that it has been identified as a Short Listed Respondent will not constitute a Contract. Only if a Respondent and the Ministry enter into a subsequent full written Contract will a Respondent acquire any legal or equitable rights or privileges relative to the goods or services List of Short Listed Respondents Not Binding A Short Listed Respondent may withdraw its name from the list of Short Listed Respondents by notifying the Ministry in writing. The Ministry, at its sole discretion, may remove a name of a Short Listed Respondent from the list of Short Listed Respondents by notifying that Respondent in writing Modification of Terms The Ministry reserves the right to modify the terms of this RFEOI at any time in its sole discretion. This includes the right to cancel this RFEOI or the subsequent RFP process with the Short Listed Respondent at any time without entering into a Contract Ownership of Responses All documents, including Responses, submitted to the Province become the property of the Province. They will be received and held in confidence by the Ministry and will be subject to the provisions of the Freedom of Information and Protection of Privacy Act Confidentiality of Information Information pertaining to the Province obtained by the Respondent as a result of participation in this project is confidential and must not be disclosed without written authorization from the Province Receipt Confirmation Form - 7 -

8 Respondents are advised to fill out and return the Receipt Confirmation Form (see attached Appendix A). All subsequent information regarding this RFEOI, including changes made to this document will be directed to Respondents who return the form Respondents Meeting No Respondents meeting is planned for this RFEOI Examination and Interpretation of Documents Each Interested Party shall review all RFEOI documents and shall promptly report and request clarification of any discrepancies, deficiencies, or errors. Any such request must be submitted at least 5 working days prior to the Closing Date. Where such requests result in a change or clarification in the RFEOI, the Ministry will prepare and issue an addendum to the RFEOI. Request for clarification shall be by written request only, either couriered, hand delivered, ed or faxed to the Ministry Contact named on the front cover of this RFEOI. Viewing information pertaining to this RFEOI includes: Donald Bridge Trans Canada Highway Value Analysis Report by JCL Consulting Ltd. January 2007; Trans Canada Highway Donald Bridges Project Business Case Evaluation Report by BC MoT March 2007; Information can be viewed, by appointment only, Monday to Friday from 8:30am to 3:00pm Pacific Standard Time, at the following Ministry Office: Ministry of Transportation and Infrastructure Southern Interior Region Columbia Street Kamloops, BC V2C 2T3 An appointment for viewing must be setup by contacting the Contact Person named on the front cover of this RFEOI by Services The Short Listed Respondent who is successful in the subsequent RFP process will become the Contractor and will be required to perform and be responsible for providing the following services (subject to the successful negotiation of the Contract): a) Design Project Management; b) Design Project Quality Management; - 8 -

9 c) Highway and drainage engineering (functional and detailed design); d) Structural engineering (conceptual and detailed design); e) Geotechnical Engineering (investigation and design); f) Traffic engineering; g) Environmental Services (investigation and mitigation strategies); h) Additional surveys as required to complete the assignment; i) Provide Value Analysis (VA) and Value Engineering (VE) facilitators, team members and materials for the VA / VE working sessions; j) Provide Road Safety Audit (RSA) Services and team members; k) Provide display materials and attend Open Houses for affected stakeholders; and l) Provide construction engineering services during tender and construction period (respond to tender and construction queries, provide shop drawing and proprietary design reviews, provide as-built record drawings etc.). The Ministry will provide the following services related to the delivery of the project: a) Property acquisition estimates; b) Property negotiations and acquisitions; c) Archeological investigations; d) Lidar mapping in CAiCE format for the Project limits; and e) Orthophotos of the Project area; f) Construction inspection; and g) CP Rail liaison during design and construction. A more detailed and complete description of the engineering services required for this project will be provided to the Short Listed Respondents within the RFP. 4. Proposed Schedule The following activities and dates are proposed by the Ministry and shall be used by the Respondents. Activity Proposed Completion Date RFEOI & RFP Process: Issue RFOI September 12, 2008 Close RFEOI October 6, 2008 Announce Short List October 20, 2008 Issue RFP to Short Listed Consultants November 7, 2008 Close RFP December 1, 2008 Select Preferred Consultant December 15, 2008 Contract in Place with Preferred Consultant January 31, 2009 Design & Construction: (tentative) 100% Functional Design Complete August 31, % Detailed Design & Tender Documents January 31, 2010 Tender March 1,

10 Activity Proposed Completion Date Completion of Construction November 30, Form of Contract Any Contract with the selected Respondent will be in accordance to the Terms and Conditions of the British Columbia Ministry of Transportation and Infrastructure s Consulting Service Contract. 6. Evaluation Criteria 6.1 Evaluation Process The Ministry will evaluate the Responses against the mandatory and desirable criteria provided below. Based on the evaluation, the Province will identify three (3) Respondents that best meet the criteria and will become the Short Listed Respondents. Subsequent to the identification of the Short Listed Respondents, the Province will issue an RFP to the Short Listed Respondents with the intent of soliciting proposals for the work and selecting a single Respondent that best meets the criteria that will be provided in the RFP. 6.2 Mandatory Criteria The following are mandatory criteria. Responses not clearly demonstrating that they meet all the mandatory criteria will receive no further consideration during the evaluation process. Criteria a) The Response must be received at the closing location by the specified closing date and time. b) The Response must be in English and must not be sent by facsimile or . c) Four (4) bound copies plus one (1) copy in pdf format on CD of the Response must be submitted. d) The Response must include a Declaration Letter which is signed by a person(s) authorized to sign on behalf of the Respondent. e) The Response must follow the specified format. 6.3 Desirable Criteria

11 Responses meeting the mandatory criteria will be evaluated against the following desirable criteria. Description Description 1. Project Understanding 15% Company understanding of design and schedule requirements 2. Quality Management 10% Commitment and process 3. Company 25% Relevant demonstrated experience Experience 4. Team Organization 10% Allocation of suitable resources and reporting structure 5. Experience for Key 25% Team member relevant experience Personnel 6. Availability & 10% Company & Staff Commitment 7. Presentation 5% Format and clarity of package Total 100% 7. Respondent s Response Response envelopes shall be clearly marked with the name and address of the respondent and include the following label: EXPRESSION OF INTEREST TO PROVIDE ENGINEERING SERVICES FOR Project Number Trans Canada Highway No.1 Donald Bridges and Approaches Conceptual and Detailed Bridge Design & Functional and Detailed Highway Design CONFIDENTIAL - DO NOT OPEN Attention to: Laurie Christiansen, P.Eng. Manager Bridge & Structural Engineering Ministry of Transportation and Infrastructure Southern Interior Region Columbia Street Kamloops, BC V2C 2T3 Four (4) bound copies of the Response, plus one (1) digital copy in PDF format, on CD shall be submitted. Responses submitted by facsimile or will not be accepted. Responses and their envelopes shall be clearly marked with the name and address of the Respondent, the Project Number, and the project title

12 Respondents shall provide their Response in a package of not more than 25 pages (8.5x11) in the main body of the package using a minimum font size of 10. All pages should be consecutively numbered. Resumes and project data sheets are not included in the 25 page limit. The following format and sequence must be followed in order to provide consistency in Respondent Responses and ensure each Response receives full consideration. Use of the following format is a mandatory criteria under the evaluation process. Transmittal/ Cover Letter (1 page) Table of Contents (1 page) Respondent s Response Declaration Letter: (1 page) - Signed by an authorized company representative - Commitment to meet all requirements including scheduled delivery times Main Body Using the Identified Headers: 1) Project Understanding (maximum 3 pages) The Response should demonstrate a clear and coherent understanding of the Project requirements and identify the opportunities and challenges that may surface during the design and construction stages. 2) Quality Management (maximum 4 pages) The Response should demonstrate the Teams ability to develop and implement an effective Quality Management System on projects of similar nature, size, scope, and complexity. Key areas that will be evaluated include, but may not be limited to: Reporting structure; Quality Control procedures; Quality Assurance procedures; and Non-compliance reporting and resolution. 3) Company Experience (maximum 5 pages) The Response should provide descriptions of similar previous relevant Ministry projects. Details should include, but may not be limited to: The name of the project; Scheduled and actual completion dates and reasons for any changes to the completion dates; A description of the project in a manner that demonstrates the relevant skills; The team members / key individuals involved and their roles in the project; Original design budget, final cost and items that influenced the additional cost, if any; and The name and contact information of the Project Manager

13 4) Team Organization/Structure (maximum 4 pages) The Response should demonstrate an effective and appropriate team organization. Key areas that will be evaluated include, but may not be limited to: Roles and responsibilities of team members; Organization and reporting structure; Management and Coordination; Lines of responsibility and reporting relationships; and Team strengths / depth and balance. 5) Key Personnel (maximum 4 pages) The Response should demonstrate that the team and its members have all the necessary skills and abilities to undertake the work that will be required to complete the detailed highway design. Key areas that will be evaluated include, but may not be limited to: Roles and responsibilities of key personnel, including managers, engineers, and technologists/technicians; Description of prior working relationships among team members; and Demonstrate relevant experience and expertise of the proposed team members. 6) Availability and Commitment (maximum 2 pages) The Response should provide appropriate information to demonstrate the company s and named staff s existing commitments and their availability for completing the project tasks in accordance with the schedule provided. APPENDICIES: Project Data Sheets including references (maximum 2 pages per project to a maximum of 10 pages) Curriculum Vitae including references (maximum 1 page per Team Member) The presentation of the response package will be evaluated on the basis that the package should be clear, concise, easy to read and comprehend, complete and in the format outlined above

14 Appendix A Receipt Confirmation Form Project Number Trans Canada Hwy. No.1 Donald Bridges and Approaches Conceptual and Detailed Bridge Design & Functional and Detailed Highway Design CLOSING DATE: 2:00 pm Pacific Time on October 6, 2008 For any further distributed information about this Request For Expression Of Interest, please return this form as soon as possible to: Laurie Christiansen, P.Eng. (Laurie.Christiansen@gov.bc.ca) or Fax: (250) Or Mail To: Ministry of Transportation and Infrastructure, Southern Interior Region Columbia Street, Kamloops, BC, V2C 2T3 COMPANY: STREET ADDRESS: CITY: POSTAL/ZIP CODE: PROVINCE/STATE: COUNTRY: MAILING ADDRESS, IF DIFFERENT: FAX NUMBER: CONTACT PERSON: ADDRESS: ( ) PHONE NUMBER: ( ) Unless it cannot be sent by , please send us any further correspondence about this Request for Expression of Interest by: Courier Collect: Courier Name and Account No. Mail Fax SIGNATURE: TITLE: 14

REQUEST FOR QUALIFICATIONS Quantity Surveyor Pre-qualified List for Partnerships British Columbia Inc. RFQ #: 3567

REQUEST FOR QUALIFICATIONS Quantity Surveyor Pre-qualified List for Partnerships British Columbia Inc. RFQ #: 3567 REQUEST FOR QUALIFICATIONS Quantity Surveyor Pre-qualified List for Partnerships British Columbia Inc. RFQ #: 3567 Submission Time: Submission Location: 2:00 p.m. (local time) on December 22, 2010 Partnerships

More information

REQUEST FOR EXPRESSIONS OF INTEREST 5006 EOI DETERRENT PROGRAM FOR SNOW GEESE CONTROL

REQUEST FOR EXPRESSIONS OF INTEREST 5006 EOI DETERRENT PROGRAM FOR SNOW GEESE CONTROL 5006 EOI REQUEST FOR EXPRESSIONS OF INTEREST 5006 EOI DETERRENT PROGRAM FOR SNOW GEESE CONTROL Responses to this Request for Expressions of Interest will be received at the Information Counter, Main Floor,

More information

EXPRESSION OF INTEREST (EOI) LONG FORM. Construction Contract Administration Services

EXPRESSION OF INTEREST (EOI) LONG FORM. Construction Contract Administration Services EXPRESSION OF INTEREST (EOI) LONG FORM Construction Contract Administration Services Generic Document for Request for Proposal (RFP) Assignments Ministry of Transportation of Ontario (MTO) December 2016

More information

South Fraser Perimeter Road Project Request For Qualifications

South Fraser Perimeter Road Project Request For Qualifications South Fraser Perimeter Road Project Request For Qualifications July 29, 2008 SUMMARY OF KEY INFORMATION RFQ TITLE The title of this RFQ is: RFQ-SFPR South Fraser Perimeter Road Project Please use this

More information

Memo. Date: November 30, 2006

Memo. Date: November 30, 2006 Memo Date: November 30, 2006 Subject: Request for Qualifications Quantity Surveying Services for Partnerships British Columbia Projects RFQ Number: 1230 Partnerships BC welcomes qualified individuals,

More information

REQUEST FOR PROPOSAL. HRIS Human Resources Information Software Fort Morgan, Colorado

REQUEST FOR PROPOSAL. HRIS Human Resources Information Software Fort Morgan, Colorado REQUEST FOR PROPOSAL HRIS Human Resources Information Software Fort Morgan, Colorado October 7, 2014 Michael Boyer Director, Human Resources and Risk Management CITY OF FORT MORGAN P.O. BOX 100 FORT MORGAN,

More information

REQUEST FOR PROPOSAL (RFP) AS NEEDED ENGINEERING DESIGN SERVICES FOR 2019, 2020 & 2021

REQUEST FOR PROPOSAL (RFP) AS NEEDED ENGINEERING DESIGN SERVICES FOR 2019, 2020 & 2021 REQUEST FOR PROPOSAL (RFP) AS NEEDED ENGINEERING DESIGN SERVICES FOR 2019, 2020 & 2021 The Washtenaw County Road Commission (WCRC) invites qualified firms to submit Proposals for As Needed Engineering

More information

Request for Proposals CONTRACTED LANDSCAPE ARCHITECTURE SERVICES

Request for Proposals CONTRACTED LANDSCAPE ARCHITECTURE SERVICES Request for Proposals CONTRACTED LANDSCAPE ARCHITECTURE SERVICES Issued October 18, 2017 DEADLINE Noon Wednesday, November 15, 2017 CONTACT: KRISTINA HANDT CITY ADMINISTRATOR 3800 Laverne Ave N Lake Elmo,

More information

Request for Proposals (RFP) First Nations Health Authority (FNHA)

Request for Proposals (RFP) First Nations Health Authority (FNHA) Request for Proposals (RFP) Scope of Service RFP # RFP issued by Leadership Development/Coaching/360 Assessment 2016RFP-09 First Nations Health Authority (FNHA) Issue date June 17, 2015 Closing date/time

More information

City of Santaquin REQUEST FOR PROPOSALS For Engineering Services for the East Side Booster Pump Station

City of Santaquin REQUEST FOR PROPOSALS For Engineering Services for the East Side Booster Pump Station City of Santaquin REQUEST FOR PROPOSALS For Engineering Services for the East Side Booster Pump Station The City of Santaquin (the City ) hereby requests competitive proposals from qualified consultants

More information

EXPRESSION OF INTEREST (EOI) LONG FORM. Planning / Engineering Services Assignment

EXPRESSION OF INTEREST (EOI) LONG FORM. Planning / Engineering Services Assignment EXPRESSION OF INTEREST (EOI) LONG FORM Planning / Engineering Services Assignment Generic Document for Request for Proposal (RFP) Assignments Contract Management Office Ministry of Transportation of Ontario

More information

Request for Quotation (RFQ) for. Conducting audit of Online Campaign for Indian Plantations for IBEF. Request for Quotation [RFQ]

Request for Quotation (RFQ) for. Conducting audit of Online Campaign for Indian Plantations for IBEF. Request for Quotation [RFQ] 1 Request for Quotation (RFQ) for Conducting audit of Online Campaign for Indian Plantations for IBEF Request for Quotation [RFQ] 20th Floor, Jawahar Vyapar Bhawan Tolstoy Marg New Delhi 110001 2 PART

More information

Request for Qualifications. Surrey Biofuel Processing Facility Project RFQ # 5587

Request for Qualifications. Surrey Biofuel Processing Facility Project RFQ # 5587 Surrey Biofuel Processing Facility Project RFQ # 5587 Issued May 16, 2013 Conformed: February 21, 2014 Page i SUMMARY OF KEY INFORMATION RFQ TITLE CONTACT PERSON The title of this RFQ is: RFQ Surrey Biofuel

More information

REQUEST FOR PROPOSALS AND STATEMENT OF QUALIFICATIONS IMPACT FEE STUDY

REQUEST FOR PROPOSALS AND STATEMENT OF QUALIFICATIONS IMPACT FEE STUDY REQUEST FOR PROPOSALS AND STATEMENT OF QUALIFICATIONS IMPACT FEE STUDY June 1, 2018 The City of Rhome is now accepting sealed Request for Proposals and Statement of Qualifications (RFQ) for New Water &

More information

RFQ Drainage Ditching and Culvert Replacement

RFQ Drainage Ditching and Culvert Replacement RFQ 2016-26 Drainage Ditching and Culvert Replacement The City of Dawson Creek requests quotes for drainage ditching and replacement of culverts in the area of 7 th Street and 122 nd Avenue. All contract

More information

Federal Buildings Initiative Qualification Requirements

Federal Buildings Initiative Qualification Requirements Federal Buildings Initiative Qualification Requirements Important Note: Companies who wish to be qualified under the Federal Buildings Initiative (FBI) and who wish to bid on a project for which a Request

More information

Request for Quotation (RFQ) for Updation of Best of India in Pharmaceuticals for India Brand Equity Foundation (IBEF)

Request for Quotation (RFQ) for Updation of Best of India in Pharmaceuticals for India Brand Equity Foundation (IBEF) Request for Quotation (RFQ) for Updation of Best of India in Pharmaceuticals for India Brand Equity Foundation (IBEF) Request for Quotation [RFQ] April 2015 India Brand Equity Foundation, Apparel House,

More information

Expression of Interest (EOI)

Expression of Interest (EOI) Expression of Interest (EOI) Rev. July 15 2002 EOI 22021 Issued: September 16, 2002 DOCUMENT IMAGING & MANAGEMENT Insurance Corporation of British Columbia Procurement & Contract Services P210-151 West

More information

Human Resources Consultant Compensation and Pay Equity Request for Proposal

Human Resources Consultant Compensation and Pay Equity Request for Proposal The Township of Nipissing 45 Beatty Street Nipissing, ON P0H 1W0 Lead Contact: Charles Barton, CAO-Clerk Email: admin@nipissingtownship.com Phone: 705-724-2144 Fax: 705-724-5385 Human Resources Consultant

More information

REQUEST FOR QUALIFICATIONS CITY ENGINEERING SERVICES

REQUEST FOR QUALIFICATIONS CITY ENGINEERING SERVICES REQUEST FOR QUALIFICATIONS CITY ENGINEERING SERVICES QUALIFICATION SUBMITTAL DATE: Monday, February 18, 2019 RFQ Number 2019-01 City of McLendon-Chisholm 1371 W. FM 550 McLendon-Chisolm, Texas 75032 972-524-2077

More information

Request for Quotation (RFQ) for IT Support Services for India Brand Equity Foundation (IBEF)

Request for Quotation (RFQ) for IT Support Services for India Brand Equity Foundation (IBEF) Request for Quotation (RFQ) for IT Support Services for India Brand Equity Foundation (IBEF) Request for Quotation [RFQ] India Brand Equity Foundation, Apparel House, 5th Floor, # 519-22, Sector 44, Gurgaon

More information

Request for Letter of Interest (Electronic Submittal Required)

Request for Letter of Interest (Electronic Submittal Required) Request for Letter of Interest (Electronic Submittal Required) Skyline Drive Engineering Design and Right-of-Way Acquisition October 2017 Page 1 of 10 Overview: Consultant selection is a Qualification-Based

More information

REQUEST FOR PROPOSAL. For Technical Contractor CanGym Revitalization City Park Drive, Suite 120 Ottawa, ON K1J 1A3

REQUEST FOR PROPOSAL. For Technical Contractor CanGym Revitalization City Park Drive, Suite 120 Ottawa, ON K1J 1A3 REQUEST FOR PROPOSAL For Technical Contractor CanGym Revitalization 1900 City Park Drive, Suite 120 Ottawa, ON K1J 1A3 Request for Proposal For Technical Contractor CanGym Revitalization Gymnastics Canada

More information

REGIONAL DISTRICT OF KITIMAT STIKINE INVITATION TO QUOTE FOR THE SUPPLY OF ROLL-OFF BINS FOR THORNHILL TRANSFER STATION. ITQ Number: FR15-005

REGIONAL DISTRICT OF KITIMAT STIKINE INVITATION TO QUOTE FOR THE SUPPLY OF ROLL-OFF BINS FOR THORNHILL TRANSFER STATION. ITQ Number: FR15-005 REGIONAL DISTRICT OF KITIMAT STIKINE INVITATION TO QUOTE FOR THE SUPPLY OF ROLL-OFF BINS FOR THORNHILL TRANSFER STATION ITQ Number: FR15-005 October 2015 TABLE OF CONTENTS 1. Eligibility to Submit a Quote...

More information

MARYLAND STADIUM AUTHORITY

MARYLAND STADIUM AUTHORITY MARYLAND STADIUM AUTHORITY REQUEST FOR QUALIFICATIONS (RFQ) GENERAL CONTRACTOR RENOVATIONS TO OPERATIONS OFFICE M&T BANK STADIUM MSA Project No. 19-013 ISSUE DATE: October 9, 2018 MARYLAND STADIUM AUTHORITY

More information

REQUEST FOR PROPOSALS FOR AN INTEGRATED PROJECT DELIVERY METHOD UTILIZING DESIGN/BUILD GUARANTEED MAXIMUM PRICE (GMP) SERVICES

REQUEST FOR PROPOSALS FOR AN INTEGRATED PROJECT DELIVERY METHOD UTILIZING DESIGN/BUILD GUARANTEED MAXIMUM PRICE (GMP) SERVICES REQUEST FOR PROPOSALS FOR AN INTEGRATED PROJECT DELIVERY METHOD UTILIZING DESIGN/BUILD GUARANTEED MAXIMUM PRICE (GMP) SERVICES Pueblo Urban Renewal Authority (PURA) Pueblo Convention Center Expansion &

More information

REQUEST FOR QUALIFICATIONS AND QUOTES 1716 VEHICLE WRAPS AND DECALS

REQUEST FOR QUALIFICATIONS AND QUOTES 1716 VEHICLE WRAPS AND DECALS OLYMPIA, WASHINGTON REQUEST FOR QUALIFICATIONS AND QUOTES 1716 VEHICLE WRAPS AND DECALS REQUEST FOR QUALIFICATIONS AND QUOTES (RFQQ) RELEASE DATE: April 13, 2017 PRE-PROPOSAL MEETING: Date: April 24, 2017

More information

CUSTOMER NAME Security Awareness Education Request for Proposal. Program Content & Hosting Services Date

CUSTOMER NAME Security Awareness Education Request for Proposal. Program Content & Hosting Services Date CUSTOMER NAME Security Awareness Education Request for Proposal Program Content & Hosting Services Date Contents SAE Project Overview... 3 SAE Vendor Qualifications... 3 Project Milestones... 3 CUSTOMER

More information

REQUEST FOR SERVICE. Project: Stakeholder Engagement Videos

REQUEST FOR SERVICE. Project: Stakeholder Engagement Videos REQUEST FOR SERVICE Project: Stakeholder Engagement Videos Release Date: September 9 th, 2017 Closing Date: Submit to: Friday September 22 nd, 2017 at 11:59 pm Natalie Surridge, Project Coordinator for

More information

REQUEST FOR QUALIFICATIONS. FOR THE PROVISION OF LEGAL SERVICES General Counsel. ISSUE DATE: December 11, DUE DATE: December 28, 2017

REQUEST FOR QUALIFICATIONS. FOR THE PROVISION OF LEGAL SERVICES General Counsel. ISSUE DATE: December 11, DUE DATE: December 28, 2017 REQUEST FOR QUALIFICATIONS FOR THE PROVISION OF LEGAL SERVICES General Counsel ISSUE DATE: December 11, 2017 DUE DATE: December 28, 2017 Issued by: Rahway Parking Authority NOTE: In the event an interested

More information

RFP # Request for Proposal Branding Services. Date: January 12, Proposals must be submitted by 3:00 PM: February 10, 2017

RFP # Request for Proposal Branding Services. Date: January 12, Proposals must be submitted by 3:00 PM: February 10, 2017 RFP #1116-1 Request for Proposal Branding Services Date: January 12, 2017 Proposals must be submitted by 3:00 PM: February 10, 2017 Purchasing Department Queens Borough Public Library 89-11 Merrick Boulevard

More information

GPTCHB Website Maintenance Request for Proposals. REQUEST FOR PROPOSALS Website Maintenance

GPTCHB Website Maintenance Request for Proposals. REQUEST FOR PROPOSALS Website Maintenance REQUEST FOR PROPOSALS Website Maintenance Proposals are due and must be received at: Great Plains Tribal Chairmen s Health Board Attention: Kristine Watts 1770 Rand Road Rapid City, South Dakota 57702

More information

ALBERTA INFRASTRUCTURE AND TRANSPORTATION REQUEST FOR QUALIFICATIONS

ALBERTA INFRASTRUCTURE AND TRANSPORTATION REQUEST FOR QUALIFICATIONS ALBERTA INFRASTRUCTURE AND TRANSPORTATION REQUEST FOR QUALIFICATIONS FOR THE DESIGN, BUILD, FINANCING, OPERATION OF NORTHEAST STONEY TRAIL CALGARY, ALBERTA, CANADA February 24, 2006 TABLE OF CONTENTS 1

More information

Request for Qualifications Statements

Request for Qualifications Statements Request for Qualifications Statements BND WATER DISTRIBUTION AND WASTEWATER TREATMENT ENGINEERING STATEMENTS ENGINEERING DESIGN SERVICES FOR BND WATER DISTRIBUTION AND WASTEWATER TREATMENT The Brownsville

More information

Request For Proposal Of Printing and Design Services. Marketing Department

Request For Proposal Of Printing and Design Services. Marketing Department Request For Proposal Of Printing and Design Services Marketing Department Released on June 3, 2016 Mosaic Youth Theatre of Detroit Printing and Design Services REQUEST FOR PROPOSAL (RFP) BACKGROUND Mosaic

More information

Village of Algonquin Request for Proposals Accounting Services

Village of Algonquin Request for Proposals Accounting Services Village of Algonquin Request for Proposals Accounting Services Issue Date: February 1, 2018 Submission Deadline: March 2, 2018 5:00 p.m. CST PROPOSALS RECEIVED AFTER THE SUBMISSION DEADLINE WILL BE RETURNED

More information

MARYLAND STADIUM AUTHORITY

MARYLAND STADIUM AUTHORITY MARYLAND STADIUM AUTHORITY REQUEST FOR QUALIFICATIONS (RFQ) DESIGN CONSULTANT FOR EXPANSION JOINT REPLACEMENT Small Business Reserve Procurement M&T BANK STADIUM MSA Project No. 19-021 ISSUE DATE: October

More information

KUDUMBASHREE STATE MISSION

KUDUMBASHREE STATE MISSION Tender No 1 ISO CERTIFICATION 2018-19 KUDUMBASHREE STATE MISSION 2nd Floor, TRIDA Rehabilitation Building, Medical College P.O., Thiruvananthapuram - 695011, Kerala. Phone: 91-471-2554714, 2554715, 2554716

More information

Request for Quotations Arras Weir Maintenance

Request for Quotations Arras Weir Maintenance Request for Quotations 2015-35 Arras Weir Maintenance The City of Dawson Creek requests written quotes for maintenance at the Arras Weir on the Kiskatinaw River, 1.7 km upstream of the Kiskatinaw Bridge

More information

REQUEST FOR QUALIFICATIONS. FOR THE PROVISION OF LEGAL SERVICES General Counsel. ISSUE DATE: August 10, DUE DATE: August 23, 2017.

REQUEST FOR QUALIFICATIONS. FOR THE PROVISION OF LEGAL SERVICES General Counsel. ISSUE DATE: August 10, DUE DATE: August 23, 2017. REQUEST FOR QUALIFICATIONS FOR THE PROVISION OF LEGAL SERVICES General Counsel ISSUE DATE: August 10, 2017 DUE DATE: August 23, 2017 Issued by: Trenton Parking Authority NOTE: In the event an interested

More information

UAF Combined Heat & Power Replacement (CPHR)

UAF Combined Heat & Power Replacement (CPHR) davis JV UAF Combined Heat & Power Replacement (CPHR) REQUEST FOR BIDS Limited 2015 Mechanical Scope PROPOSALS DUE: THURSDAY JULY 2 ND, 2015 2:00PM LOCAL ALASKA TIME Submit to: Haskell Corporation /Davis

More information

Contact:

Contact: HORSESHOE LANDS ABSTRACT Stoney Nakoda Developments is seeking a development partner for the Horseshoe Lands in the MD Bighorn, Alberta. Located in the sought after Bow Corridor Kananaskis Region, this

More information

REQUEST FOR QUALIFICATIONS. FOR THE PROVISION OF LEGAL SERVICES General Counsel. ISSUE DATE: December 20, DUE DATE: January 11, 2019.

REQUEST FOR QUALIFICATIONS. FOR THE PROVISION OF LEGAL SERVICES General Counsel. ISSUE DATE: December 20, DUE DATE: January 11, 2019. NOTE: In the event an interested firm has downloaded these specifications from the TPA website, you are responsible for providing the TPA via email at Trentonparkingph@aol.com your contact information,

More information

Quad Cities Chamber of Commerce. Request for Proposals for HUMAN RESOURCES MANAGED SERVICES

Quad Cities Chamber of Commerce. Request for Proposals for HUMAN RESOURCES MANAGED SERVICES Quad Cities Chamber of Commerce Request for Proposals for HUMAN RESOURCES MANAGED SERVICES Project Manager: Leslie Anderson, Vice President Finance landerson@quadcitieschamber.com 1601 River Dr., Suite

More information

Request for Qualifications: City Engineering and Architectural Services

Request for Qualifications: City Engineering and Architectural Services Request for Qualifications: City Engineering and Architectural Services The City of Clever, Missouri ( City ) is pleased to issue this Request for Qualifications ( RFQ ) for City Engineering and Architectural

More information

PROFESSIONAL CONSULTANT SERVICES REQUEST FOR QUALIFICATIONS (RFQ)

PROFESSIONAL CONSULTANT SERVICES REQUEST FOR QUALIFICATIONS (RFQ) PROFESSIONAL CONSULTANT SERVICES REQUEST FOR QUALIFICATIONS (RFQ) MARCH 2018 INTRODUCTION AND BACKGROUND The City of Keller is in search of the most qualified firms to provide professional expertise and

More information

Request for Proposals (RFP)

Request for Proposals (RFP) Request for Proposals (RFP) Scope of Service RFP # RFP issued by Human Resource Services Assessment Corporate Information Systems (CIS) 2016RFP-23 First Nations Health Authority (FNHA) Issue date August

More information

Request for Proposals for Marketing Services

Request for Proposals for Marketing Services Request for Proposals for Marketing Services Proposal Deadline: 3:00pm CST, Friday, December 8 th, 2017 Engineers Geoscientists Manitoba, an Association requesting marketing plan development proposals

More information

Guide to the Letters of Assurance in the B.C. Building Code 2006 December, 2010 Edition 5

Guide to the Letters of Assurance in the B.C. Building Code 2006 December, 2010 Edition 5 Guide to the Letters of Assurance in the B.C. Building Code 2006 December, 2010 Edition 5 Building & Safety Standards Branch Ministry of Public Safety & Solicitor General Province of British Columbia GUIDE

More information

Request for Quotation (RFQ) for E-book conversion of Booklet on Achievements of Department of Commerce

Request for Quotation (RFQ) for E-book conversion of Booklet on Achievements of Department of Commerce Request for Quotation (RFQ) for E-book conversion of Booklet on Achievements of Department of Commerce Request for Quotation [RFQ] India Brand Equity Foundation, 20 th Floor, Jawahar Vyapar Bhawan Tolstoy

More information

REQUEST FOR QUALIFICATIONS FOR CONSTRUCTION MANAGER SERVICES AT RISK WITH GUARANTEED MAXIMUM PRICE

REQUEST FOR QUALIFICATIONS FOR CONSTRUCTION MANAGER SERVICES AT RISK WITH GUARANTEED MAXIMUM PRICE REQUEST FOR QUALIFICATIONS FOR CONSTRUCTION MANAGER SERVICES AT RISK WITH GUARANTEED MAXIMUM PRICE Memphis Cook Convention Center Renovation City of Memphis, Department of Housing and Community Development

More information

Request for Qualifications Professional Services For. Wood Recycling Center Facility. Contract Number: C City of Chattanooga, Tennessee

Request for Qualifications Professional Services For. Wood Recycling Center Facility. Contract Number: C City of Chattanooga, Tennessee Request for Qualifications Professional Services For Wood Recycling Center Facility Contract Number: C-17-017-101 City of Chattanooga, Tennessee December 2017 Section 1 Introduction REQUEST FOR QUALIFICATIONS

More information

Subject: Statement of Qualifications for Public Safety Building Design

Subject: Statement of Qualifications for Public Safety Building Design March 5, 2010 Subject: Statement of Qualifications for Public Safety Building Design The City of Porterville seeks Statements of Qualification (SOQ) from qualified architectural and engineering firms for

More information

Ohio Public Employees Retirement System. Request for Proposal

Ohio Public Employees Retirement System. Request for Proposal Ohio Public Employees Retirement System For: Consulting Services for Development of the Business Intelligence & Analytics Office Date: 9/11/2017 Project Name: Business Intelligence & Analytics Program

More information

SIMLAW Seed CoMpAny LIMIted

SIMLAW Seed CoMpAny LIMIted SIMLAW Seed CoMpAny LIMIted TENDER DOCUMENT TENDER FOR SALE OF BOARDED MOTOR VEHICLES AND BEANS TENDER REF: SSC/T/DC/10/2018/2019 TENDER CLOSING & OPENING DATE: -16 th NOVEMBER, 2018 SIMLAW SEED COMPANY

More information

CONSTRUCTION MANAGEMENT SERVICES

CONSTRUCTION MANAGEMENT SERVICES DrAFTDRAFTdd EXHIBIT 1 CONSTRUCTION MANAGEMENT SERVICES REQUEST FOR QUALIFICATIONS () SELECTION PROCESS School District of Lee County, Florida TABLE OF CONTENTS 1. INTRODUCTION 1 Lobbying 2 2. REQUEST

More information

REGISTRATION FOR SUPPLY, DELIVERY, INSTALLATION, REPAIR AND MAINTENANCE OF AIR CONDITIONERS SERVICE PROVIDERS

REGISTRATION FOR SUPPLY, DELIVERY, INSTALLATION, REPAIR AND MAINTENANCE OF AIR CONDITIONERS SERVICE PROVIDERS UNIVERSITY OF EMBU REGISTRATION FOR SUPPLY, DELIVERY, INSTALLATION, REPAIR AND MAINTENANCE OF AIR CONDITIONERS SERVICE PROVIDERS UoEm/04/2017-2019 CLOSING DATE: APRIL 18TH 2017 AT 11.00 AM Table of Contents

More information

DATE: 02/05/2018. REQUEST FOR PROPOSAL: No. RFP/2018/UNHCR/PSP/MENA/002 FOR THE ESTABLISHMENT OF A FRAME AGREEMENT FOR THE PROVISION OF

DATE: 02/05/2018. REQUEST FOR PROPOSAL: No. RFP/2018/UNHCR/PSP/MENA/002 FOR THE ESTABLISHMENT OF A FRAME AGREEMENT FOR THE PROVISION OF DATE: 02/05/2018 REQUEST FOR PROPOSAL: No. RFP/2018/UNHCR/PSP/MENA/002 FOR THE ESTABLISHMENT OF A FRAME AGREEMENT FOR THE PROVISION OF Recruitment, on-boarding and staff administration services United

More information

Invitation to Tender. Development Legal Services. August 2015

Invitation to Tender. Development Legal Services. August 2015 Development Legal Services August Contents 1. Important notices... 3 1.1. Confidentiality... 3 1.2. Accuracy of information and liability of SLH... 3 1.3. Canvassing... 4 1.4. Non-collusion... 5 1.5. Copyright...

More information

REQUEST FOR PROPOSAL CWA TRAINING INITIATIVE. February 13, 2018

REQUEST FOR PROPOSAL CWA TRAINING INITIATIVE. February 13, 2018 REQUEST FOR PROPOSAL CWA TRAINING INITIATIVE February 13, 2018-1 - Table of Contents 1. Summary... 3 2. Background of Organization... 3 3. Proposal Guidelines and Requirements... 3-4 4. Contract Terms...

More information

REQUEST FOR QUALIFICATIONS FOR CONSTRUCTION MANAGER AT RISK (CMAR) SERVICES WITH GUARANTEED MAXIMUM PRICE

REQUEST FOR QUALIFICATIONS FOR CONSTRUCTION MANAGER AT RISK (CMAR) SERVICES WITH GUARANTEED MAXIMUM PRICE CAYUCOS SANITARY DISTRICT 200 Ash Avenue P.O. Box 333, Cayucos, California 93430-0333 www.cayucossd.org 805-995-3290 REQUEST FOR QUALIFICATIONS FOR CONSTRUCTION MANAGER AT RISK (CMAR) SERVICES WITH GUARANTEED

More information

REQUEST FOR PROPOSAL For CEO Search Listening Sessions Bid Number: March 22, 2019

REQUEST FOR PROPOSAL For CEO Search Listening Sessions Bid Number: March 22, 2019 Fresno Economic Opportunities Commission (Fresno EOC) is soliciting proposals to establish a contract with one (1) qualified and experienced vendor to conduct listening sessions in Fresno EOC Target Areas,

More information

CITY OF PASCO REQUEST FOR PROPOSAL TO PROVIDE SERVICES FOR THE Urban Forestry Plan and Urban Forest Inventory

CITY OF PASCO REQUEST FOR PROPOSAL TO PROVIDE SERVICES FOR THE Urban Forestry Plan and Urban Forest Inventory DEPARTMENT OF Administrative and Community Services 525 N Third Avenue Pasco, WA 99301 Phone 509.543.5757 Fax 509.543.5758 CITY OF PASCO REQUEST FOR PROPOSAL TO PROVIDE SERVICES FOR THE 2018 Urban Forestry

More information

Oxford & Area Trails Association River Philip Bridge Construction, Oxford, N.S Project No.: OATA003 SECTION 1.0 INSTRUCTION TO BIDDERS

Oxford & Area Trails Association River Philip Bridge Construction, Oxford, N.S Project No.: OATA003 SECTION 1.0 INSTRUCTION TO BIDDERS 1.1 INSTRUCTION TO BIDDERS Oxford & Area Trails Association River Philip Bridge Construction, Project No.: OATA003 INSTRUCTIONS TO BIDDERS August 7, 2015 SECTION 1.0 INSTRUCTION TO BIDDERS 1.2 TENDER DOCUMENTS

More information

EXPRESSION OF INTEREST (EOI) Consultancy Services for carrying out

EXPRESSION OF INTEREST (EOI) Consultancy Services for carrying out North Eastern Development Finance Corporation Ltd. NEDFi House, G.S. Road, Dispur, Guwahati-781 006, Assam, India. Ph. No.: +91-361-2222200, Fax No. : +91-361-2237733 Website: www.nedfi.com EXPRESSION

More information

REAL ESTATE MARKET STUDY SERVICES

REAL ESTATE MARKET STUDY SERVICES Request for Qualifications for REAL ESTATE MARKET STUDY SERVICES Required by MISSOURI HOUSING DEVELOPMENT COMMISSION RESPONSES DUE: Friday, May 23, 2014 by 4:30 P.M. Central Time SECTION I: INTRODUCTORY

More information

ADMINISTRATIVE DIRECTIVE #CS-04

ADMINISTRATIVE DIRECTIVE #CS-04 HILLSBOROUGH COUNTY Office of the County Administrator ADMINISTRATIVE DIRECTIVE #CS-04 SUBJECT: EFFECTIVE DATE: UTILITY COORDINATION PROCEDURES FOR HILLSBOROUGH COUNTY CONSTRUCTION PROJECTS WITHIN COUNTY

More information

REQUEST FOR PROPOSALS

REQUEST FOR PROPOSALS REQUEST FOR PROPOSALS FOR COMPENSATION STUDY Proposals Due: November 3, 2016, 4:00 PM 1.0 OBJECTIVE SECTION 1 SUBMITTAL PROCEDURES & DEADLINE The City of Signal Hill is seeking proposals from qualified

More information

REQUEST FOR PROPOSALS (RFP) FOR ARCHITECTURAL SERVICES CLEARWATER PUBLIC SCHOOLS EWING PUBLIC SCHOOLS NELIGH-OAKDALE PUBLIC SCHOOLS

REQUEST FOR PROPOSALS (RFP) FOR ARCHITECTURAL SERVICES CLEARWATER PUBLIC SCHOOLS EWING PUBLIC SCHOOLS NELIGH-OAKDALE PUBLIC SCHOOLS REQUEST FOR PROPOSALS (RFP) FOR ARCHITECTURAL SERVICES CLEARWATER PUBLIC SCHOOLS EWING PUBLIC SCHOOLS NELIGH-OAKDALE PUBLIC SCHOOLS 1. REQUEST FOR PROPOSALS. Clearwater Public Schools, Ewing Public Schools,

More information

1 August 2018 RFQ No11543 REQUEST FOR QUOTATION (RFQ)

1 August 2018 RFQ No11543 REQUEST FOR QUOTATION (RFQ) 1 August 2018 RFQ No11543 REQUEST FOR QUOTATION (RFQ) RFQ Description : Server Operating Systems Upgrade Closing Date and Time : 08 August 2018 Briefing Session Date and Time Site Inspection : N/A : N/A

More information

PETALUMA HISTORICAL LIBRARY AND MUSEUM Project # C

PETALUMA HISTORICAL LIBRARY AND MUSEUM Project # C REQUEST FOR PROPOSALS CITY OF PETALUMA, CALIFORNIA PETALUMA HISTORICAL LIBRARY AND MUSEUM Project # C16201304 KEY ELEMENTS & ACTIVITIES Complete Comprehensive Analysis & Scope Development Complete Design

More information

Please have your pre-qualification document submitted before closing at 3:00:00 p.m. Local Time Thursday January 29, 2009.

Please have your pre-qualification document submitted before closing at 3:00:00 p.m. Local Time Thursday January 29, 2009. PREQUALIFICATION OF GENERAL CONTRACTOR, MECHANICAL SUBCONTRACTORS AND ELECTRICAL SUBCONTRACTORS FOR CONSTRUCTION OF THE BROCKVILLE WPCC SECONDARY TREATMENT UPGRADE Please have your pre-qualification document

More information

Selection of the Regional Consultant List

Selection of the Regional Consultant List LOCAL DESIGN SERVICES AGREEMENT (LDSA) CONSULTANT SELECTION PROCEDURE A Request For Qualifications (RFQ) pursuant to the ad in the New York State Contract Reporter was made available to any architecture/engineering

More information

REQUEST FOR QUALIFICATIONS LEGAL SERVICES FOR THE SOUTHEAST OVERTOWN/PARK WEST COMMUNITY REDEVELOPMENT AGENCY RFQ NUMBER 17-01

REQUEST FOR QUALIFICATIONS LEGAL SERVICES FOR THE SOUTHEAST OVERTOWN/PARK WEST COMMUNITY REDEVELOPMENT AGENCY RFQ NUMBER 17-01 REQUEST FOR QUALIFICATIONS LEGAL SERVICES FOR THE SOUTHEAST OVERTOWN/PARK WEST COMMUNITY REDEVELOPMENT AGENCY RFQ NUMBER 17-01 ISSUE DATE Friday, July 21, 2017 SUBMISSION DATE AND TIME Tuesday, August

More information

REQUEST FOR QUALIFICATIONS FOR CONSTRUCTION MANAGER AT RISK FOR THE NEW

REQUEST FOR QUALIFICATIONS FOR CONSTRUCTION MANAGER AT RISK FOR THE NEW REQUEST FOR QUALIFICATIONS FOR CONSTRUCTION MANAGER AT RISK FOR THE NEW Fire Station No. 1, Fire Administration, Training/Emergency Operations, and Public Works Service Center DUE April 17, 2017 BY 4:00

More information

Township of Severn REQUEST FOR PROPOSAL. Architectural & Professional Services Fire Station Replacement

Township of Severn REQUEST FOR PROPOSAL. Architectural & Professional Services Fire Station Replacement Township of Severn REQUEST FOR PROPOSAL Architectural & Professional Services Fire Station Replacement Deadline for proposal submission is June 15, 2017 at 2:00 p.m. Contact Person: Tim Cranney Director

More information

Invitation to tender. Provision of External Audit Services

Invitation to tender. Provision of External Audit Services Invitation to tender for the Provision of External Audit Services Tender return date: 10.00 am on 2 nd May 2017 Return to: Enquiries to: Address: Clerk to the Corporation Alison Rowland (arowland@sussexcoast.ac.uk)

More information

Date: Telephone: Company Name: Address: City: State: Zip Code: Contact Person: Title: Authorized Signature:

Date: Telephone: Company Name: Address: City: State: Zip Code: Contact Person: Title: Authorized Signature: SUBMISSION INFORMATION Kenton County Fiscal Court P.O. Box 792 303 Court Street, Room 207 Covington, Kentucky 41012-0792 QUALIFICATION: Radio Project Phase II RFQ OPENING DATE: December 7, 2015 TIME: 2:00

More information

Request for Proposal. 4229P PeopleSoft HCM Technical Consulting Services

Request for Proposal. 4229P PeopleSoft HCM Technical Consulting Services Request for Proposal 4229P PeopleSoft HCM Technical Consulting Services 1. Introduction The City of Richmond (the City ) requires the services of a PeopleSoft technical consultant (the Consultant ) to

More information

Request for Proposal. Labour Supply-Demand Study. Reference Number: Issued: May 9, 2016 Responses Due: May 23, 2016

Request for Proposal. Labour Supply-Demand Study. Reference Number: Issued: May 9, 2016 Responses Due: May 23, 2016 Labour Supply-Demand Study Reference Number: 1605-01 Issued: May 9, 2016 Responses Due: May 23, 2016 Calgary Economic Development Ltd. 731 1 st Street SE Calgary, AB T2G 2G9 Phone: (403) 221-7831 or 1-888-222-5855

More information

T 1.1: Tender Notice and Invitation to Tender SECTION 1: NOTICE TO TENDERERS 1. INVITATION TO BID

T 1.1: Tender Notice and Invitation to Tender SECTION 1: NOTICE TO TENDERERS 1. INVITATION TO BID T1.1 Tender Notice and Invitation to Tender SECTION 1: NOTICE TO TENDERERS 1. INVITATION TO BID Responses to this Tender [hereinafter referred to as a Tender] are requested from persons, companies, close

More information

Invitation for Bid - Standard Office Furniture / Task Chair

Invitation for Bid - Standard Office Furniture / Task Chair Invitation for Bid - Bid#2016-09-001 Instructions to Bidders 1. General Information Rice University is issuing this Invitation for Bid (IFB) for the procurement of goods and/or trade services as described

More information

RFQ. Request for Qualifications Phase One. Renovation of City Owned Homes CITY OF BEREA, OHIO. Mayor Cyril Kleem

RFQ. Request for Qualifications Phase One. Renovation of City Owned Homes CITY OF BEREA, OHIO. Mayor Cyril Kleem RFQ Request for Qualifications Phase One Renovation of City Owned Homes CITY OF BEREA, OHIO Mayor Cyril Kleem City of Berea, Ohio Project: Renovation of City Owned Homes Criteria Engineer: Antonio C. Armagno,

More information

City of Coquitlam. Request for Proposals RFP No IBM Maximo Licensing and Services

City of Coquitlam. Request for Proposals RFP No IBM Maximo Licensing and Services Request for Proposals RFP No. 18-06-05 IBM Maximo Licensing and Services Issue Date: August 24, 2018 RFP 18-06-05 IBM Maximo Licensing and Services Table of Contents Page SUMMARY OF KEY INFORMATION...

More information

REQUEST FOR PROPOSAL FOR POLICE OPERATIONS STUDY LOWER SAUCON TOWNSHIP

REQUEST FOR PROPOSAL FOR POLICE OPERATIONS STUDY LOWER SAUCON TOWNSHIP REQUEST FOR PROPOSAL FOR POLICE OPERATIONS STUDY LOWER SAUCON TOWNSHIP Released on July 21, 2016 Police Operations Study REQUEST FOR PROPOSAL ( RFP ) 1. PURPOSE OF THE STUDY The Township of Lower Saucon

More information

Survey Services Rev. 0 Bid # Scope of Work

Survey Services Rev. 0 Bid # Scope of Work Scope of Work I. Scope of Solicitation II. Instructions to Offerors III. Scope of Work / Specifications IV. Terms and Conditions - Special V. Appendices to Scope of Work (if required) VI. Bidding Schedule

More information

Ohio Public Employees Retirement System. Request for Proposal

Ohio Public Employees Retirement System. Request for Proposal Ohio Public Employees Retirement System For: Application Performance Monitoring Software Date: March 23, 2018 277 East Town Street Columbus, Ohio 43215 1-800-222-PERS (7377) www.opers.org PLEASE NOTE:

More information

Request for Proposals

Request for Proposals Request for Proposals Comprehensive Parks, Trails, & Recreation Master Plan Services Section 1 Proposal Guidelines PURPOSE This RFP is soliciting proposals for a Professional Planning Consultant Service

More information

City of Dawson Creek Request for Proposals No

City of Dawson Creek Request for Proposals No City of Dawson Creek Request for Proposals No. 2011-29 SANITARY SEWER MASTER PLAN The City of Dawson Creek is requesting proposals for the creation of a Sanitary Sewer Master Plan. All contract documents

More information

Expression of Interest (EOI) Architectural Services for the Design of a Sports Complex and a potential Community Centre

Expression of Interest (EOI) Architectural Services for the Design of a Sports Complex and a potential Community Centre Expression of Interest (EOI) 2018-01 Architectural Services for the Design of a Sports Complex and a potential Community Centre Documents Available: July 16 th, 2018 4:00 P.M. local time Closing Date:

More information

City of Moline, IL. Request for Proposal Employee Wellness Program for the City of Moline, Illinois. Issue date: June 13, 2014

City of Moline, IL. Request for Proposal Employee Wellness Program for the City of Moline, Illinois. Issue date: June 13, 2014 City of Moline, IL Request for Proposal Employee Wellness Program for the City of Moline, Illinois Issue date: June 13, 2014 Closing date and time: A complete copy of the sealed proposal must be received

More information

Town of Bennington, Vermont Pleasant Street and School Street Sidewalk Installation STP EH08(11)

Town of Bennington, Vermont Pleasant Street and School Street Sidewalk Installation STP EH08(11) , Vermont Pleasant Street and School Street Sidewalk Installation STP EH08(11) Request for Qualifications Construction Inspection and Testing Services Issued: January 3, 2017 Due: January 24, 2017 I. INTRODUCTION

More information

1.1 Detailed working concept which allows us to examine the technical aspects in the light of the project objective.

1.1 Detailed working concept which allows us to examine the technical aspects in the light of the project objective. 1. Content of the bid Your bid should contain the following information: 1.1 Detailed working concept which allows us to examine the technical aspects in the light of the project objective. This includes:

More information

Deadline for documents submission June 11, 2009 before 12:00 hours (local time)

Deadline for documents submission June 11, 2009 before 12:00 hours (local time) United Nations Development Programme Date: 26 May 2009 Expression of Interest Pre-Qualification for Civil Works Ref: PRQ/KRT/09/001- R1 United Nations Development Programme (UNDP), Sudan office announces

More information

ROAD SAFETY AUDIT GUIDELINES. Table of Contents

ROAD SAFETY AUDIT GUIDELINES. Table of Contents April 1, 2004 Table of Contents 1.0 Road Safety Audit Policy...2 2.0 The Purpose of the Guidelines...2 3.0 Road Safety Audit Objectives...2 4.0 Legal Issues...3 5.0 Road Safety Audit Procedures...4 5.1

More information

DATE: 05/03/2018. REQUEST FOR PROPOSAL: No. RFP/2018/UNHCR/PSP/MENA/001 FOR THE ESTABLISHMENT OF A FRAME AGREEMENT FOR THE PROVISION OF

DATE: 05/03/2018. REQUEST FOR PROPOSAL: No. RFP/2018/UNHCR/PSP/MENA/001 FOR THE ESTABLISHMENT OF A FRAME AGREEMENT FOR THE PROVISION OF DATE: 05/03/2018 REQUEST FOR PROPOSAL: No. RFP/2018/UNHCR/PSP/MENA/001 FOR THE ESTABLISHMENT OF A FRAME AGREEMENT FOR THE PROVISION OF Recruitment and staff administration services in Gulf Cooperation

More information

REQUEST FOR QUALIFICATIONS FOR THE PROVISION OF CLAIMS LITIGATION INVOICE REVIEW SERVICES GSMJIF. ISSUE DATE: October 2, 2017

REQUEST FOR QUALIFICATIONS FOR THE PROVISION OF CLAIMS LITIGATION INVOICE REVIEW SERVICES GSMJIF. ISSUE DATE: October 2, 2017 NOTE: The GSMJIF will consider qualifications only from firms or organizations that have demonstrated the capability and willingness to provide high quality services in the manner described in this Request

More information

REQUEST FOR QUALIFICATIONS

REQUEST FOR QUALIFICATIONS NOTE: The City of New Brunswick Parking Authority will consider proposals only from firms or organizations that have demonstrated the capability and willingness to provide high quality services in the

More information