Document B101 TM. Standard Form of Agreement Between Owner and Architect

Document B101 TM 2007 Standard Form of Agreement Between Owner and Architect AGREEMENT made as of the day of in the year Two Thousand and BETWEEN the Architect s client identified as the Owner: Capitol Region Education Council 111 Charter Oak Avenue Hartford, CT 06106 and the Architect: for the following Project: ADDITIONS AND DELETIONS: The author of this document has added information needed for its completion. The author may also have revised the text of the original AIA standard form. An Additions and Deletions Report that notes added information as well as revisions to the standard form text is available from the author and should be reviewed. A vertical line in the left margin of this document indicates where the author has added necessary information and where the author has added to or deleted from the original AIA text. This document has important legal consequences. Consultation with an attorney is encouraged with respect to its completion or modification. The Owner and Architect agree as follows. Init. / AIA Document B101 2007 (formerly B151 1997). Copyright 1974, 1978, 1987, 1997 and 2007 by The American Institute of Architects. All rights reserved. WARNING: This AIA Document is protected by U.S. Copyright Law and International Treaties. Unauthorized reproduction or distribution of this AIA Document, or any portion of it, may result in severe civil and criminal penalties, and will be prosecuted to the maximum extent possible under the law. This document was produced by AIA software at 12:50:08 on 02/24/2016 under Order No.6204946249_1 which expires on 08/17/2016, and is not for resale. 1

Init. / TABLE OF ARTICLES 1 INITIAL INFORMATION 2 ARCHITECT S RESPONSIBILITIES 3 SCOPE OF ARCHITECT S BASIC SERVICES 4 ADDITIONAL SERVICES 5 OWNER S RESPONSIBILITIES 6 COST OF THE WORK 7 COPYRIGHTS AND LICENSES 8 CLAIMS AND DISPUTES 9 TERMINATION OR SUSPENSION 10 MISCELLANEOUS PROVISIONS 11 COMPENSATION 12 SPECIAL TERMS AND CONDITIONS 13 SCOPE OF THE AGREEMENT EXHIBIT A INITIAL INFORMATION ARTICLE 1 INITIAL INFORMATION 1.1 This Agreement is based on the Initial Information set forth in (Paragraphs deleted) (i) this Article 1; (ii) that certain Request for Qualifications/Proposals for Architectural Services for issued by the Owner for the Project, a copy of which is attached hereto as Exhibit A and made a part hereof (the "RFQ/P"); and (iii) that certain document prepared by the Architect and submitted to the Owner in response to the RFQ/P dated and entitled "Qualifications/Proposal " (the "Architect Proposal"). To the extent of conflicts between the terms and conditions of the RFQ/P and the Architect Proposal, the terms and conditions of the RFQ/P shall govern and prevail. 1.2 The Owner s anticipated dates for commencement of design services and Project completion are set forth below:.1 Commencement of design services date: (Paragraph deleted).2 Project completion date: 1.3 The Owner and Architect may rely on the Initial Information. Both parties, however, recognize that such information may materially change and, in that event, the Owner and the Architect shall appropriately adjust the schedule, the Architect s services and the Architect s compensation as provided in this Agreement. 1.4 Where reference is made in this Agreement to a provision of AIA Document A201 2007 or any other AIA document or provision, the reference refers to that document or provision as amended by the Owner and, if applicable, any other party to such document, and as amended and supplemented by other provisions of the Contract Documents. Notwithstanding the foregoing, a copy of the AIA Document A201 2007 as amended by the Owner for AIA Document B101 2007 (formerly B151 1997). Copyright 1974, 1978, 1987, 1997 and 2007 by The American Institute of Architects. All rights reserved. WARNING: This AIA Document is protected by U.S. Copyright Law and International Treaties. Unauthorized reproduction or distribution of this AIA Document, or any portion of it, may result in severe civil and criminal penalties, and will be prosecuted to the maximum extent possible under the law. This document was produced by AIA software at 12:50:08 on 02/24/2016 under Order No.6204946249_1 which expires on 08/17/2016, and is not for resale. 2

Init. / the Project is attached here to as Exhibit B and made a part hereof and all references in this Agreement to AIA Document A201 2007 shall mean the document attached hereto as Exhibit B. ARTICLE 2 ARCHITECT S RESPONSIBILITIES 2.1 The Architect s Services consist of the services the Architect is required to perform under this Agreement, and, unless inconsistent with the instructions, guidance, and direction of the Owner, all professional services usually and customarily performed in conjunction with, and in furtherance of, such services. 2.2 The Architect shall be responsible for the performance of the Architect s Services as an independent contractor and in a good and workmanlike manner (i) consistent this Agreement; (ii) consistent with the instructions, guidance and direction of the Owner; (iii) consistent with the highest prevailing applicable professional or industry standards; (iv) consistent with sound architectural practices; and (v) as expeditiously as is consistent with such professional skill and care, the orderly progress of the Project, the instructions of the Owner and this Agreement (the standards of this Section 2.2 shall be referred to herein as the "Architect s Standard of Care"). 2.2.1 The Architect shall exercise the Architect s Standard of Care in performing all aspects of the Architect s Services. All references in this Agreement or in the Contract Documents to the knowledge, inference, reliance, awareness, determination, belief, observation, recognition or discovery of the Architect or reference to any similar term shall include the knowledge, inference, reliance, awareness, determination, belief, observation and recognition the Architect would have obtained upon the exercise of the Architect s Standard of Care. 2.3 The Architect shall be responsible for the performance of the Architect s Services in compliance with all applicable laws, rules, regulations, ordinances, codes, orders and permits of all federal, state and local government bodies, agencies, authorities and courts having jurisdiction over the Project and with the Conditions as defined in Subsection 2.3.1. 2.3.1 The "Conditions" are all statutory and regulatory requirements and all guidelines and standards imposed on the Project by the Agencies, as defined in Sections 2.3.2 and 2.3.3. 2.3.2 The "Agencies" are the Owner, the Department of Education of the State of Connecticut, including, without limitation, the Bureau of School Facilities (the "Department") and all other governmental authorities having regulatory or administrative jurisdiction over the Project and all representatives or designees of the Department or such other governmental authorities. The term "Agencies" shall also include any individuals or entities designated by the Department or such other governmental authorities or by the Owner to monitor or oversee compliance of the Project s energy and environmental design with the requirements of the Department or such other governmental authorities. 2.3.3 The term "Agencies" shall also include any individual or entity not described in Section 2.3.2 from whom the Owner intends to request certification of the Project s energy and environmental design, to the extent the Architect is required, under this Agreement, to provide services relating to such certification. 2.3.4 The Architect understands that performance of the Architect s Services will require communication with the Agencies and with individuals designated by the Agencies, and the Architect will, at no additional cost to the Owner, so communicate and take all steps reasonably necessary to ensure compliance with the Conditions. 2.4 Except with the Owner s knowledge and consent, the Architect shall not engage in any activity, or accept any employment, interest or contribution that would reasonably appear to compromise the Architect s professional judgment with respect to this Project. 2.5 The Architect shall maintain the types and amounts of insurance specified in this Section 2.5. The Architect shall maintain such insurance until five (5) years after Substantial Completion, or for any other period specified in this Agreement. The Architect shall require its consultants and subcontractors to maintain the same types of insurance the Architect is required to maintain under this Agreement, in amounts approved by the Owner. The Owner shall be named an additional insured on the Commercial General Liability and Automobile Liability insurance of the Architect and its subcontractors and consultants. Before commencing the Architect s Services, the Architect shall file with the Owner certificates of insurance for the required insurance and shall update such certificates throughout the duration of this Agreement and during any additional period specified in this Agreement. AIA Document B101 2007 (formerly B151 1997). Copyright 1974, 1978, 1987, 1997 and 2007 by The American Institute of Architects. All rights reserved. WARNING: This AIA Document is protected by U.S. Copyright Law and International Treaties. Unauthorized reproduction or distribution of this AIA Document, or any portion of it, may result in severe civil and criminal penalties, and will be prosecuted to the maximum extent possible under the law. This document was produced by AIA software at 12:50:08 on 02/24/2016 under Order No.6204946249_1 which expires on 08/17/2016, and is not for resale. 3

Init. / Certificates of professional liability insurance shall bear the endorsement Not to be canceled without thirty (30) days prior written notice to Owner. All subcontractors are subject to the same requirements. It is your responsibility to be sure that subcontractors provide acceptable evidence of insurance. Architect s general liability policy must be endorsed with ISO Endorsement CG 20 26 0704 (or equivalent) or ISO Endorsement CG 20 33 07 04 (or equivalent), and ISO Endorsement CG 20 37 07 04 (or equivalent). These form numbers must be specifically referenced on the certificate of insurance. If Architect s insurance company uses another form to provide Owner with additional insured status on Architect s policies, copies of those forms must be provided in advance with the certificate for review and approval by Owner. Evidence of compliance with these requirements is with the ACCORD form 25, "Certificate of Liability Insurance". Certificates shall be sent to the following address: Capitol Region Education Council, 111 Charter Oak Avenue, Hartford, CT 06106. The following is a list of the types and amounts of insurance coverage required of the Architect under this Agreement:.1 COMMERCIAL GENERAL LIABILITY: $1,000,000 per occurrence/$2,000,000 aggregate bodily injury/property damage. The CGL policy must include coverage for: liability from premises and operations; liability from products or completed operations; liability from actions of independent contractors and liability assumed by contract..2 AUTOMOBILE LIABILITY: $1,000,000 per accident for bodily injury/property damage, including hired and non-owned vehicles..3 WORKERS COMPENSATION: Statutory..4 PROFESSIONAL LIABILITY.1 Minimum coverage for each occurrence: $2,000,000.2 Minimum annual coverage: $5,000,000.3 Maximum deductible: $100,000.4 Extended reporting period for five (5) years following the date of Substantial Completion.5 Umbrella Policy: As per the terms of the RFQ/P ARTICLE 3 SCOPE OF ARCHITECT S BASIC SERVICES 3.1 The Architect s Basic Services consist of those services described in Article 3 and, unless inconsistent with the instructions, guidance, and direction of the Owner, all professional services usually and customarily performed in conjunction with, and in furtherance of, those services including, but not limited to, structural, mechanical, and electrical engineering services. 3.1.1 The Architect shall manage the Architect s Services, consult with the Owner and the Agencies, research applicable design criteria, attend Project meetings, communicate with members of the Project team and report progress to the Owner. 3.1.2 The Architect shall coordinate the Architect s Services with those services provided by the Owner and the Owner s consultants. Unless notified otherwise by the Owner in writing, the Architect shall be entitled to rely on the accuracy and completeness of services and information furnished by the Owner and the Owner s consultants. The Architect shall provide prompt written notice to the Owner if the Architect becomes aware of any error, omission or inconsistency in such services or information. AIA Document B101 2007 (formerly B151 1997). Copyright 1974, 1978, 1987, 1997 and 2007 by The American Institute of Architects. All rights reserved. WARNING: This AIA Document is protected by U.S. Copyright Law and International Treaties. Unauthorized reproduction or distribution of this AIA Document, or any portion of it, may result in severe civil and criminal penalties, and will be prosecuted to the maximum extent possible under the law. This document was produced by AIA software at 12:50:08 on 02/24/2016 under Order No.6204946249_1 which expires on 08/17/2016, and is not for resale. 4

Init. / 3.1.3 Within ten (10) days after the date of this Agreement, the Architect shall submit for the Owner s approval a schedule for the performance of the Architect s Services. Said schedule shall be timed to obtain all required State Department of Education approvals no later than. Said schedule assumes that the Owner shall obtain third party review of the proposed construction documents. The schedule initially shall include anticipated dates for the commencement of construction and for Substantial Completion of the Work. The schedule shall include allowances for periods of time required for the Owner s review, for the performance of the Owner s consultants, and for approval of submissions by the Agencies. Once approved by the Owner, time limits established by the schedule shall not, except for reasonable cause, be exceeded by the Architect or Owner. With the Owner s approval, the Architect shall adjust the schedule, if necessary as the Project proceeds until the commencement of construction. Time is of the essence in this Agreement and the Architect will be bound by the schedule and will not deviate from or adjust the schedule without the Owner s express written consent which consent the Owner shall not unreasonably withhold for deviations or adjustments to the extent necessary due to factors outside the Architect s control. The Architect shall update the schedule to incorporate any deviations or adjustments approved by the Owner and shall provide the Owner with such updated schedule. 3.1.4 The Architect shall not be responsible for an Owner s directive or substitution made without notice to the Architect or to which the Architect has timely objected in writing, which objection shall include an explanation of such objection. 3.1.5 The Architect shall, at appropriate times, consult with the Agencies whose approval of the Construction Documents is necessary for the successful funding and completion of the Project and with the entities providing utility services to the Project. In designing the Project, the Architect shall respond to applicable design requirements imposed by such the Agencies and by the entities providing utility services. 3.1.6 The Architect shall assist the Owner in connection with the Owner s responsibility for filing documents required for the approval of the Agencies. 3.2 SECTION OMITTED. 3.3 SCHEMATIC DESIGN PHASE SERVICES (Paragraphs deleted) 3.3.1 The Schematic Design Phase shall commence upon written notice by the Owner to the Architect. 3.3.2 The Architect shall review the program, schedule, budget for the Cost of the Work, proposed procurement or delivery method, and other Initial Information furnished by the Owner; the Project site; information furnished for, and produced during, the Pre-Approval Services, the local approval process, and the approval for funding from the Department; all applicable laws, codes and regulations; and the Conditions (all the foregoing referred to herein as the "Schematic Design Phase Information"). The Architect shall, as required, consult with the Agencies on an ongoing basis during the Schematic Design Phase. 3.3.3 The Architect shall review and prepare a preliminary evaluation of the elements of the Schematic Design Phase Information each in terms of the other, to ascertain the requirements of the Project. The Architect shall notify the Owner of (1) any inconsistencies discovered in the information, and (2) other information or consulting services that may be reasonably needed for the Project. 3.3.4 The Architect shall present its preliminary evaluation to the Owner and shall discuss with the Owner alternative approaches to design and construction of the Project, including the feasibility of incorporating environmentally responsible design approaches. The Architect shall reach an understanding with the Owner regarding the requirements of the Project. The Architect shall submit a written copy of the understanding to the Owner for the Owner s written approval (the "Project s Requirements"). 3.3.5 Based on the Project s Requirements, the Architect shall prepare and present for the Owner s approval a preliminary design illustrating the scale and relationship of the Project components. 3.3.6 Based on the Owner s approval of the preliminary design, the Architect shall prepare Schematic Design Documents for the Owner s approval. The Schematic Design Documents shall consist of drawings and other AIA Document B101 2007 (formerly B151 1997). Copyright 1974, 1978, 1987, 1997 and 2007 by The American Institute of Architects. All rights reserved. WARNING: This AIA Document is protected by U.S. Copyright Law and International Treaties. Unauthorized reproduction or distribution of this AIA Document, or any portion of it, may result in severe civil and criminal penalties, and will be prosecuted to the maximum extent possible under the law. This document was produced by AIA software at 12:50:08 on 02/24/2016 under Order No.6204946249_1 which expires on 08/17/2016, and is not for resale. 5

documents including a site plan, if appropriate, and preliminary building plans, sections and elevations; and may include some combination of study models, perspective sketches, or digital modeling. The Architect shall consult with the Agencies to determine the requirements to be incorporated in the Schematic Design Documents. Preliminary selections of major building systems and construction materials shall be noted on the drawings or described in writing. 3.3.7 The Architect shall incorporate in the Schematic Design Documents and all subsequent Design Documents the designs required to comply with those of the Conditions relating to energy and environmental design criteria and standards, and all energy and environmental design criteria and standards otherwise requested by the Owner under this Agreement. The Architect shall further consider other environmentally responsible design alternatives during the schematic phase not included in the Conditions and not otherwise requested by the Owner, such as, to the extent not included in the Conditions and not otherwise requested by the Owner, material choices and building orientation, together with other considerations based on program and aesthetics, in developing a design that is consistent with the Owner s program, schedule and budget for the Cost of the Work. The Owner may obtain other environmentally responsible design services under Article 4. 3.3.8 The Architect shall consider the value of alternative materials, building systems and equipment, together with other considerations based on program and aesthetics in developing a design for the Project that is consistent with the Owner s program, schedule and budget for the Cost of the Work. 3.3.9 The Architect and the Contractor shall each prepare and submit for the Owner s approval, separate written itemized estimates of the Cost of the Work prepared in accordance with Article 6 and based on the Schematic Design Documents. 3.3.10 The Architect shall submit the Schematic Design Documents to the Owner, and request the Owner s approval. The Architect shall revise the Schematic Design Documents as requested by the Owner, shall transmit the revised documents to the Contractor for a revised estimate of the Cost of the Work based on such revisions and shall submit such revised Schematic Design Documents and such updated estimate for the Owner s approval. 3.3.11 The Architect shall, upon the Owner s request, attend some or all conferences with the Agencies without limitation. 3.4 DESIGN DEVELOPMENT PHASE SERVICES 3.4.1 The Design Development Phase shall commence upon written notice by the Owner to the Architect. 3.4.2 Based on the Owner s approval of the Schematic Design Documents, and on the Owner s authorization of any adjustments in the Project requirements and the budget for the Cost of the Work, the Architect shall prepare Design Development Documents for the Owner s approval. The Design Development Documents shall illustrate and describe the development of the approved Schematic Design Documents and shall consist of drawings and other documents including plans, sections, elevations, typical construction details, and diagrammatic layouts of building systems to fix and describe the size and character of the Project as to architectural, structural, mechanical and electrical systems, and such other elements as may be appropriate. The Design Development Documents shall also include outline specifications that identify major materials and systems and establish in general their quality levels. 3.4.3 The Architect and the Contractor shall each update their estimate of the Cost of the Work submitted to the Owner pursuant to Section 3.3.9 based on the Design Development Documents. 3.4.4 The Architect shall submit the Design Development documents to the Owner, advise the Owner of any adjustments to the estimate of the Cost of the Work, and request the Owner s approval. The Architect shall revise the Design Development Documents as requested by the Owner. (Paragraph deleted) 3.5 CONSTRUCTION DOCUMENTS PHASE SERVICES 3.5.1 The Construction Documents Phase shall commence upon the Owner s written notice to the Architect. Init. / AIA Document B101 2007 (formerly B151 1997). Copyright 1974, 1978, 1987, 1997 and 2007 by The American Institute of Architects. All rights reserved. WARNING: This AIA Document is protected by U.S. Copyright Law and International Treaties. Unauthorized reproduction or distribution of this AIA Document, or any portion of it, may result in severe civil and criminal penalties, and will be prosecuted to the maximum extent possible under the law. This document was produced by AIA software at 12:50:08 on 02/24/2016 under Order No.6204946249_1 which expires on 08/17/2016, and is not for resale. 6

Init. / 3.5.2 Based on the Owner s approval of the Design Development Documents, and on the Owner s authorization of any adjustments in the Project requirements and the budget for the Cost of the Work, the Architect shall prepare Construction Documents for the Owner s approval. The Construction Documents shall illustrate and describe the further development of the approved Design Development Documents and shall consist of Drawings and Specifications setting forth in detail the quality levels of materials and systems and other requirements for the construction of the Work including all information required to obtain all permits, certifications, and approvals necessary to complete the Project. The Owner and Architect acknowledge that in order to construct the Work the Contractor will provide additional information, including Shop Drawings, Product Data, Samples and other similar submittals, which the Architect shall review in accordance with Section 3.7.4. (Paragraphs deleted) 3.5.3 The Architect shall incorporate into the Construction Documents the design requirements of the Agencies. (Paragraphs deleted) 3.5.4 During the development of the Construction Documents, the Architect shall assist the Owner in the development and preparation of the following: (1) bidding and procurement information that describes the time, place and conditions of bidding, including bidding or proposal forms; and (2) the Conditions of the Contract for Construction (General, Supplementary and other Conditions). The Architect shall also compile a project manual that includes the Conditions of the Contract for Construction and Specifications, bidding requirements and sample forms. 3.5.5 Any design errors or omissions in the Construction Documents furnished by the Architect will be promptly corrected by the Architect at no cost to the Owner, and the Architect will indemnify the Owner for all third party claims, suits and damages, if any, resulting from the Architect s negligent acts, errors or omissions. The Owner s approval, acceptance, use of, or payment for, all or any part of the Architect s Services hereunder or of the Project itself shall in no way alter the Architect s obligations or the Owner s rights hereunder. If, due to the Architect s negligence, omission or failure to perform in accordance with the terms of this Agreement, a required item or component of the Project is omitted from the Construction Documents or if, due to such negligence, omission or failure, the Construction Documents must be modified through a Change Order, the Architect shall be responsible for paying the cost required to add or modify such item or component to the Project, excluding the reasonable cost that would have been incurred by the Owner at the time of the original bid for such Project item or component to the extent that such item or component would have been required and included in the original Construction Documents. In no event shall the Owner pay more than once for an item or component of the Project. 3.5.6 The Architect shall assist the Owner in obtaining the necessary approvals to begin the Bidding Phase. Such assistance shall include attending some or all meetings with the Agencies without limitation, producing any documents and providing any services reasonably required of the Architect and requested of the Owner by the Agencies, and, upon the Owner s written approval, making any adjustments to the Construction Documents requested by the Agencies. 3.6 BIDDING PHASE SERVICES 3.6.1 The Bidding Phase shall commence upon written notice from the Owner to the Architect. (Paragraphs deleted) 3.6.2 Bidding Documents shall consist of all documents to comply with bidding requirements and the proposed Contract Documents. (Paragraphs deleted) 3.6.3 The Architect shall assist the Owner in bidding the Project by preparing responses to questions from prospective bidders and providing clarifications and interpretations of the Bidding Documents to all prospective bidders in the form of addenda. (Paragraphs deleted) 3.6.4 The Architect shall consider requests for substitutions, if the Bidding Documents permit substitutions, and shall upon the Owner s written approval prepare and distribute addenda identifying approved substitutions to all prospective bidders. (Paragraphs deleted) AIA Document B101 2007 (formerly B151 1997). Copyright 1974, 1978, 1987, 1997 and 2007 by The American Institute of Architects. All rights reserved. WARNING: This AIA Document is protected by U.S. Copyright Law and International Treaties. Unauthorized reproduction or distribution of this AIA Document, or any portion of it, may result in severe civil and criminal penalties, and will be prosecuted to the maximum extent possible under the law. This document was produced by AIA software at 12:50:08 on 02/24/2016 under Order No.6204946249_1 which expires on 08/17/2016, and is not for resale. 7

Init. / 3.6.5 In the event the bids exceed the Owner s budget for the Cost of the Work, the Architect, in consultation with the Owner and based upon the Owner s authorization regarding any adjustments in the Project requirements and the Owner s budget for the Cost of the Work, shall as part of the Architect s Basic Services make adjustments to and revised the Bidding Documents, including, without limitation, the Construction Documents, for the Owner s approval until such time as bids are obtained that comply with the Owner s budget for the Cost of the Work. 3.7 CONSTRUCTION PHASE SERVICES 3.7.1 GENERAL 3.7.1.1 The Architect s responsibility to provide Construction Phase Services commences upon written notice from the Owner to the Architect and terminates, except to the extent otherwise provided in this Agreement, on the date that is six months after the date of occupancy. 3.7.1.2 The Architect shall provide administration of the Contract between the Owner and the Contractor as set forth below and in AIA Document A201 2007. Modifications or supplements made to such General Conditions of the Contract for Construction by the Owner or Contractor shall, to the extent such modifications or supplements may affect the Architect s rights and responsibilities and are inconsistent with this Agreement, be subject to the Architect s reasonable approval, which approval shall not be unreasonably withheld, conditioned or delayed. In the event of a conflict between the provisions of the AIA Document A201 2007 and this Agreement regarding the rights and responsibilities of the Architect, the provisions of this Agreement shall govern. 3.7.1.3 The Architect shall advise and consult with the Owner during the Construction Phase Services. The Architect shall have authority to act on behalf of the Owner only to the extent provided in this Agreement. The Architect shall not have control over, charge of, or responsibility for the construction means, methods, techniques, sequences or procedures, or for safety precautions and programs in connection with the Work, nor shall the Architect be responsible for the Contractor s failure to perform the Work in accordance with the requirements of the Contract Documents; provided, however, that nothing herein shall absolve the Architect of responsibility for means, methods, techniques, sequences or procedures specified in the Contract Documents or otherwise specified by the Architect. The Architect shall be responsible for the Architect s negligent acts or omissions and for the negligent acts or omissions of the Architect s consultants and subcontractors and for the failure of the Architect, and the Architect s consultants and subcontractors to comply with the requirements of this Agreement, but shall not have control over or charge of, and shall not be responsible for, acts or omissions of any other persons or entities performing portions of the Work, including the Contractor and the Contractor s subcontractors. 3.7.1.4 At the conclusion of the Construction Phase and based upon information furnished by the Contractor, the Architect shall prepare and furnish to the Owner a complete record of set drawings and specifications depicting the Project as modified during construction, in CADD format acceptable to the Owner. In addition, the Architect shall deliver to the Owner a complete set of Construction Documents in CADD format acceptable to the Owner. 3.7.2 EVALUATIONS OF THE WORK 3.7.2.1 The Architect shall visit the site at intervals appropriate to the stage of construction, but no less than twice weekly, including regularly scheduled site meetings and visits, to become familiar with the progress and quality of the portion of the Work completed, if the Work observed is being performed in a manner indicating that the Work, when fully completed, will be in accordance with the Contract Documents. However, the Architect shall not be required to make exhaustive or continuous on-site inspections to check the quality or quantity of the Work. On the basis of the site visits, the Architect shall keep the Owner reasonably informed about the progress and quality of the portion of the Work completed, and inform the Owner in writing of (1) known deviations from the Contract Documents and from the most recent construction schedule submitted by the Contractor, and (2) defects and deficiencies observed in the Work. (Paragraph deleted) 3.7.2.2 The Architect has the authority to reject Work that does not conform to the Contract Documents. Whenever the Architect considers it necessary or advisable, the Architect shall have the authority to require inspection or testing of the Work in accordance with the provisions of the Contract Documents, whether or not such Work is fabricated, installed or completed. However, neither this authority of the Architect nor a decision made in good faith either to exercise or not to exercise such authority shall give rise to a duty or responsibility of the Architect to the Contractor, Subcontractor, material and equipment suppliers, their agents or employees or other persons or entities performing portions of the Work. AIA Document B101 2007 (formerly B151 1997). Copyright 1974, 1978, 1987, 1997 and 2007 by The American Institute of Architects. All rights reserved. WARNING: This AIA Document is protected by U.S. Copyright Law and International Treaties. Unauthorized reproduction or distribution of this AIA Document, or any portion of it, may result in severe civil and criminal penalties, and will be prosecuted to the maximum extent possible under the law. This document was produced by AIA software at 12:50:08 on 02/24/2016 under Order No.6204946249_1 which expires on 08/17/2016, and is not for resale. 8

Init. / (Paragraph deleted) 3.7.2.3 The Architect shall interpret and decide matters concerning performance under, and requirements of, the Contract Documents on written request of either the Owner or Contractor. The Architect s response to such requests shall be made in writing within any time limits agreed upon or otherwise with reasonable promptness typically within seven days. 3.7.2.4 Interpretations and decisions of the Architect shall be consistent with the intent of and reasonably inferable from the Contract Documents and shall be in writing or in the form of drawings. When making such interpretations and decisions, the Architect shall endeavor to secure faithful performance by both Owner and Contractor, shall not show partiality to either, and shall not be liable for results of those interpretations or decisions rendered in good faith and that were necessitated by a reason other than an act or omission of the Architect. The Architect s decisions on matters relating to aesthetic effort shall be final if consistent with the intent expressed in the Contract Documents. (Paragraph deleted) 3.7.2.5 Unless the Owner and Contractor designate another person to serve as an Initial Decision Maker, as that term is defined in AIA Document A201 2007, the Architect shall render initial decisions on Claims between the Owner and Contractor as provided in the Contract Documents. (Paragraph deleted) 3.7.3 CERTIFICATES FOR PAYMENT TO CONTRACTOR (Paragraph deleted) 3.7.3.1 The Architect shall review the amounts due the Contractor and shall certify and issue certificates in such amounts as the Architect determines to be due. Such certifications by the Architect shall be recommendations only, subject to the Owner s approval for payment. The Architect s certification for payment shall constitute a representation to the Owner, based on the Architect s evaluation of the Work as provided in Section 3.7.2 and on the data comprising the Contractor s Application for Payment, that, to the best of the Architect s knowledge, information and belief, the Work has progressed to the point indicated and that the quality of the Work is in accordance with the Contract Documents. The foregoing representations are subject (1) to an evaluation of the Work for conformance with the Contract Documents upon Substantial Completion, (2) to results of subsequent tests and inspections, (3) to correction of minor deviations from the Contract Documents prior to completion, and (4) to specific qualifications expressed by the Architect in writing at the time of certification. 3.7.3.2 The issuance of a Certificate for Payment shall not be a representation that the Architect has (1) made exhaustive or continuous on-site inspections to check the quality or quantity of the Work, (2) reviewed construction means, methods, techniques, sequences or procedures, (3) reviewed copies of requisitions received from Subcontractors or material suppliers and other data requested by the Owner to substantiate the Contractor s right to payment, or (4) ascertained how or for what purpose the Contractor has used money previously paid on account of the Contract Sum. (Paragraph deleted) 3.7.3.3 The Architect shall maintain a record of the Applications and Certificates for Payment. 3.7.4 SUBMITTALS (Paragraph deleted) 3.7.4.1 The Architect shall review the Contractor s submittal schedule and shall not unreasonably delay or withhold approval. The Architect s action in reviewing submittals shall be taken in accordance with the approved submittal schedule or, in the absence of an approved submittal schedule, with reasonable promptness while allowing sufficient time in the Architect s professional judgment to permit adequate review. 3.7.4.2 In accordance with the Architect-approved submittal schedule, the Architect shall review and approve or take other appropriate action upon the Contractor s submittals such as Shop Drawings, Product Data and Samples, but only for the limited purpose of assuring conformity with information given and the design concept expressed in the Contract Documents. The Architect shall return duplicate submittal copies to the Contractor in such number as the Contractor requires. Review of such submittals is not for the purpose of determining the accuracy and completeness of other information such as dimensions, quantities, and installation or performance of equipment or AIA Document B101 2007 (formerly B151 1997). Copyright 1974, 1978, 1987, 1997 and 2007 by The American Institute of Architects. All rights reserved. WARNING: This AIA Document is protected by U.S. Copyright Law and International Treaties. Unauthorized reproduction or distribution of this AIA Document, or any portion of it, may result in severe civil and criminal penalties, and will be prosecuted to the maximum extent possible under the law. This document was produced by AIA software at 12:50:08 on 02/24/2016 under Order No.6204946249_1 which expires on 08/17/2016, and is not for resale. 9

systems, which are the Contractor s responsibility. The Architect s review shall not constitute approval of safety precautions or, of those construction means, methods, techniques, sequences or procedures that are not specified in the Contract Documents or otherwise specified by the Architect. The Architect s approval of a specific item shall not indicate approval of an assembly of which the item is a component. (Paragraph deleted) 3.7.4.3 If the Contract Documents specifically require the Contractor to provide professional design services or certifications by a design professional related to systems, materials or equipment, the Architect shall specify the appropriate performance and design criteria that such services must satisfy. The Architect shall review shop drawings and other submittals related to the Work designed or certified by the design professional retained by the Contractor that bear such professional s seal and signature when submitted to the Architect. The Architect shall be entitled to rely upon the adequacy, accuracy and completeness of the services, certifications and approvals performed or provided by such design professionals. 3.7.4.4 The Architect shall review and respond to requests for information about the Contract Documents. The Architect shall set forth in the Contract Documents the requirements for requests for information. Requests for information shall include, at a minimum, a detailed written statement that indicates the specific Drawings or Specifications in need of clarification and the nature of the clarification requested. The Architect s response to such requests shall be made in writing within any time limits agreed upon, or otherwise with reasonable promptness, typically within seven days. If appropriate, the Architect shall prepare and issue supplemental Drawings and Specifications in response to requests for information. 3.7.4.5 The Architect shall maintain a record of submittals and copies of submittals supplied by the Contractor in accordance with the requirements of the Contract Documents. 3.7.5 CHANGES IN THE WORK 3.7.5.1 The Architect may authorize minor changes in the Work that are consistent with the intent of the Contract Documents and do not involve an adjustment in the Contract Sum or an extension of the Contract Time. The Architect shall review proposed changes in the Work and Change Orders for the Owner s approval and execution in accordance with the Contract Documents. 3.7.5.2 The Architect shall maintain records relative to changes in the Work. 3.7.6 PROJECT COMPLETION 3.7.6.1 The Architect shall conduct inspections to determine the date or dates of Substantial Completion and the date of final completion; issue Certificates of Substantial Completion; receive from the Contractor and forward to the Owner, for the Owner s review and records, written warranties and related documents required by the Contract Documents and assembled by the Contractor; and issue a final Certificate for Payment based upon a final inspection indicating the Work complies with the requirements of the Contract Documents. 3.7.6.2 The Architect s inspections shall be conducted with the Owner to check conformance of the Work with the requirements of the Contract Documents and to verify the accuracy and completeness of the list submitted by the Contractor of Work to be completed or corrected and to prepare for the Owner a written list of observable items, materials, or systems that are defective or that require additional Work or replacement by the Contractor. 3.7.6.3 When the Work is found to be substantially complete, the Architect shall inform the Owner in writing of the balance of the Contract Sum remaining to be paid the Contractor, including the amount to be retained from the Contract Sum, if any, for final completion or correction of the Work. 3.7.6.4 The Architect shall forward to the Owner the following information received from the Contractor: (1) consent of surety or sureties, if any, to reduction in or partial release of retainage or the making of final payment; (2) affidavits, receipts, releases and waivers of liens or bonds indemnifying the Owner against liens; and (3) any other documentation required of the Contractor under the Contract Documents. 3.7.6.5 Upon request of the Owner, and prior to the expiration of one year from the date of Substantial Completion, the Architect shall, without additional compensation, conduct meetings with the Owner and the Init. / AIA Document B101 2007 (formerly B151 1997). Copyright 1974, 1978, 1987, 1997 and 2007 by The American Institute of Architects. All rights reserved. WARNING: This AIA Document is protected by U.S. Copyright Law and International Treaties. Unauthorized reproduction or distribution of this AIA Document, or any portion of it, may result in severe civil and criminal penalties, and will be prosecuted to the maximum extent possible under the law. This document was produced by AIA software at 12:50:08 on 02/24/2016 under Order No.6204946249_1 which expires on 08/17/2016, and is not for resale. 10

Owner s commissioning agent to review the facility operations and performance. The number of such meetings shall be determined by the Owner as the Owner deems necessary for the Project. 3.7.6.6 Upon request of the Owner, the Architect will cooperate and assist the Owner and the Department during any audit of the Project as conducted by the Owner or the Department at any time after Substantial Completion. ARTICLE 4 BASIC SERVICES AND ADDITIONAL SERVICES 4.1 (Paragraphs deleted) Notwithstanding anything to the contrary, (i) the Architect shall provide the services designated below as the responsibility of the Architect as included in the Basic Services and at no other additional cost to the Owner and (ii) any services made necessary by the act or omission of the Architect, its consultants or subcontractors shall be provided by the Architect as Basic Services, at no additional cost to the Owner. 4.1.1 Programming Owner/Architect 4.1.2 Multiple preliminary designs Architect 4.1.3 Measured drawings Architect 4.1.4 Existing facilities surveys Architect 4.1.5 Site Evaluation and Planning (B203 2007) Architect 4.1.6 Building information modeling Architect 4.1.7 Civil engineering Architect 4.1.8 Landscape design Architect 4.1.9 Architectural Interior Design (B252 2007) Architect Architect/Owner/Cont ractor 4.1.10 Value Analysis (B204 2007) 4.1.11 Detailed cost estimating Architect/Contractor 4.1.12 On-site project representation Architect 4.1.13 Conformed construction documents Not applicable 4.1.14 As-designed record drawings Architect 4.1.15 As-constructed record drawings Architect 4.1.16 Post occupancy evaluation Owner 4.1.17 Facility Support Services (B210 2007) Architect 4.1.18 Tenant-related services Not applicable 4.1.19 Coordination of Owner s consultants Architect 4.1.20 Telecommunications/data design Architect 4.1.21 Security Evaluation and Planning Architect (B206 2007) 4.1.22 Commissioning (B211 2007) Owner 4.1.23 Extensive environmentally responsible design Architect 4.1.24 LEED Certification (B214 2007) Architect 4.1.25 Fast-track design services Architect 4.1.26 Historic Preservation (B205 2007) Not applicable Architect/Owner 4.1.27 Furniture, Finishings, and Equipment Design/Bid (B253 2007) 4.1.28 Land Survey Services Owner 4.1.30 Environmental Studies and Reports Owner 4.1.31 Owner-Supplied Data Coordination Owner 4.1.32 Schedule Development and Monitoring Owner 4.1.33 Construction Management Contractor 41.34 Special Inspections Architect 4.1.35 Traffic Report & STC Submission Architect 4.1.36 Wetland Delineation Architect 4.1.37 Color Renderings Architect 4.1.38 Implement Re-check Comments Architect Init. / AIA Document B101 2007 (formerly B151 1997). Copyright 1974, 1978, 1987, 1997 and 2007 by The American Institute of Architects. All rights reserved. WARNING: This AIA Document is protected by U.S. Copyright Law and International Treaties. Unauthorized reproduction or distribution of this AIA Document, or any portion of it, may result in severe civil and criminal penalties, and will be prosecuted to the maximum extent possible under the law. This document was produced by AIA software at 12:50:08 on 02/24/2016 under Order No.6204946249_1 which expires on 08/17/2016, and is not for resale. 11

4.1.39 Preparation of the Statement of Special Inspection Architect 4.2 Section Omitted. 4.3 Additional Services may be provided after execution of this Agreement, without invalidating the Agreement. Except for services required due to the fault of the Architect, any Additional Services provided in accordance with this Section 4.3 shall entitle the Architect to compensation pursuant to Section 11.3 and an appropriate adjustment in the Architect s schedule. The Architect shall perform all services requested by the Owner. Services requested by the Owner or recognized to be necessary after execution of this Agreement are presumed to be included within Basic Services unless clearly shown to not be so included. Notwithstanding the foregoing, If the Architect believes a service requested by the Owner or recognized to be necessary after execution of this Agreement is an Additional Service, prior to such performance, the Owner and the Architect, solely after notice from the Architect, given within five (5) days of the Owner s request, shall meet to determine if such services are within the Basic Services or Additional Services. If the Architect fails to submit such notice, the Architect shall be deemed to have waived any right to additional compensation for such services and the same shall be deemed part of the Basic Services. 4.3.1 Upon recognizing the need to perform the following Additional Services, to the extent such services are not included in the Basic Services, the Architect shall notify the Owner with reasonable promptness and explain the facts and circumstances giving rise to the need. The Architect shall not proceed to provide the following services to the extent not included in the Basic Services, until the Architect receives the Owner s written authorization:.1 Services necessitated by a material change in the Initial Information, previous instructions or approvals given by the Owner, or a material change in the Project including, but not limited to, size, quality, complexity, the Owner s schedule or budget for Cost of the Work, or procurement or delivery method;.2 Changing or editing previously prepared Instruments of Service necessitated by the enactment or revision of codes, laws or regulations or official interpretations;.3 Services necessitated by decisions of the Owner not rendered in a timely manner or any other failure of performance on the part of the Owner or the Owner s consultants or contractors; (Paragraph deleted).4 Preparation of the design and documentation for significant alternate bid or proposal requests proposed by the Owner; (Paragraph deleted).5 Preparation for, and attendance at a dispute resolution proceeding or legal proceeding, except where the Architect is party thereto;.6 Evaluation of the qualifications of bidders or persons providing proposals; or.7 Consultation concerning replacement of Work resulting from fire or other cause during construction. 4.3.2 To avoid delay in the Construction Phase, the Architect shall provide the following Additional Services and, to the extent not included in the Basic Services, notify the Owner with reasonable promptness, and explain the facts and circumstances giving rise to the need. If the Owner subsequently determines that all or parts of those services are not required, the Owner shall give prompt written notice to the Architect, and the Owner shall have no further obligation to compensate the Architect for those services:.1 Reviewing a Contractor s submittal out of sequence from the submittal schedule agreed to by the Architect;.2 Responding to the Contractor s requests for information that are not prepared in accordance with the Contract Documents or where such information is available to the Contractor from a careful study and comparison of the Contract Documents, field conditions, other Owner-provided information, Contractor-prepared coordination drawings, or prior Project correspondence or documentation;.3 Preparing Change Orders and Construction Change Directives that require evaluation of Contractor s proposals and supporting data, or the preparation or revision of Instruments of Service;.4 Evaluating an extensive number of Claims as the Initial Decision Maker;.5 Evaluating substitutions proposed by the Owner or Contractor and making subsequent revisions to Instruments of Service resulting therefrom; or Init. / AIA Document B101 2007 (formerly B151 1997). Copyright 1974, 1978, 1987, 1997 and 2007 by The American Institute of Architects. All rights reserved. WARNING: This AIA Document is protected by U.S. Copyright Law and International Treaties. Unauthorized reproduction or distribution of this AIA Document, or any portion of it, may result in severe civil and criminal penalties, and will be prosecuted to the maximum extent possible under the law. This document was produced by AIA software at 12:50:08 on 02/24/2016 under Order No.6204946249_1 which expires on 08/17/2016, and is not for resale. 12